Submission for OMB Review; Certain Federal Acquisition Regulation Part 36 Construction Contract Requirements, 17469-17470 [2024-05107]
Download as PDF
<![CDATA[
Federal Register / Vol. 89, No. 48 / Monday, March 11, 2024 / Notices
Dated: March 6, 2024.
Sarah L. Stewart,
Deputy General Counsel.
[FR Doc. 2024–05165 Filed 3–7–24; 11:15 am]
Board of Governors of the Federal Reserve
System.
Michele Taylor Fennell,
Deputy Associate Secretary of the Board.
BILLING CODE P
[FR Doc. 2024–05122 Filed 3–8–24; 8:45 am]
BILLING CODE 6210–01–P
FEDERAL RESERVE SYSTEM
DEPARTMENT OF DEFENSE
ddrumheller on DSK120RN23PROD with NOTICES1
Change in Bank Control Notices;
Acquisitions of Shares of a Bank or
Bank Holding Company
GENERAL SERVICES
ADMINISTRATION
The notificants listed below have
applied under the Change in Bank
Control Act (Act) (12 U.S.C. 1817(j)) and
225.41 of the Board’s Regulation Y (12
CFR 225.41) to acquire shares of a bank
or bank holding company. The factors
that are considered in acting on the
applications are set forth in paragraph 7
of the Act (12 U.S.C. 1817(j)(7)).
The public portions of the
applications listed below, as well as
other related filings required by the
Board, if any, are available for
immediate inspection at the Federal
Reserve Bank(s) indicated below and at
the offices of the Board of Governors.
This information may also be obtained
on an expedited basis, upon request, by
contacting the appropriate Federal
Reserve Bank and from the Board’s
Freedom of Information Office at
https://www.federalreserve.gov/foia/
request.htm. Interested persons may
express their views in writing on the
standards enumerated in paragraph 7 of
the Act.
Comments regarding each of these
applications must be received at the
Reserve Bank indicated or the offices of
the Board of Governors, Ann E.
Misback, Secretary of the Board, 20th
Street and Constitution Avenue NW,
Washington, DC 20551–0001, not later
than March 26, 2024.
A. Federal Reserve Bank of Kansas
City (Jeffrey Imgarten, Assistant Vice
President) 1 Memorial Drive, Kansas
City, Missouri 64198–0001. Comments
can also be sent electronically to
KCApplicationComments@kc.frb.org:
1. Jeffry Albers, Wisner, Nebraska; to
retain voting shares of Citizens National
Corporation, and thereby indirectly
retain voting shares of Citizens State
Bank, both of Wisner, Nebraska.
2. Amy Skovsende, Omaha, Nebraska;
Kayla Roth Kuxhausen, West Point,
Nebraska; Traci Ebel, Wisner, Nebraska;
and Tyler Roth, Bucyrus, Kansas; to
become members of the Roth family
control group, a group acting in concert,
to retain voting shares of Citizens
National Corporation, and thereby
indirectly retain voting shares of
Citizens State Bank, both of Wisner,
Nebraska.
VerDate Sep<11>2014
18:24 Mar 08, 2024
Jkt 262001
NATIONAL AERONAUTICS AND
SPACE ADMINISTRATION
[OMB Control No. 9000–0064; Docket No.
2024–0053; Sequence No. 1]
Submission for OMB Review; Certain
Federal Acquisition Regulation Part 36
Construction Contract Requirements
Department of Defense (DOD),
General Services Administration (GSA),
and National Aeronautics and Space
Administration (NASA).
ACTION: Notice.
AGENCY:
Under the provisions of the
Paperwork Reduction Act, the
Regulatory Secretariat Division has
submitted to the Office of Management
and Budget (OMB) a request to review
and approve a revision of a previously
approved information collection
requirement regarding certain Federal
Acquisition Regulation (FAR) part 36
construction contract requirements.
DATES: Submit comments on or before
April 10, 2024.
ADDRESSES: Written comments and
recommendations for this information
collection should be sent within 30 days
of publication of this notice to
www.reginfo.gov/public/do/PRAMain.
Find this particular information
collection by selecting ‘‘Currently under
Review—Open for Public Comments’’ or
by using the search function.
FOR FURTHER INFORMATION CONTACT:
Zenaida Delgado, Procurement Analyst,
at telephone 202–969–7207, or
zenaida.delgado@gsa.gov.
SUPPLEMENTARY INFORMATION:
SUMMARY:
A. OMB Control Number, Title, and
Any Associated Form(s)
9000–0064, Certain Federal
Acquisition Regulation Part 36
Construction Contract Requirements.
B. Need and Uses
DoD, GSA, and NASA are combining
OMB Control Nos. by FAR part. This
consolidation is expected to improve
industry’s ability to easily and
efficiently identify burdens associated
with a given FAR part. This review of
PO 00000
Frm 00098
Fmt 4703
Sfmt 4703
17469
the information collections by FAR part
allows improved oversight to ensure
there is no redundant or unaccounted
for burden placed on industry. Lastly,
combining information collections in a
given FAR part is also expected to
reduce the administrative burden
associated with processing multiple
information collections.
This justification supports the
extension of OMB Control No. 9000–
0064 and combines it with the
previously approved information
collection under OMB Control No.
9000–0062, with the new title ‘‘Certain
Federal Acquisition Regulation Part 36
Construction Contract Requirements’’.
Upon approval of this consolidated
information collection, OMB Control
No. 9000–0062 will be discontinued.
The burden requirements previously
approved under the discontinued
number will be covered under OMB
Control No. 9000–0064.
This clearance covers the information
that contractors must submit to comply
with the following FAR requirements:
• FAR 52.236–5, Material and
Workmanship. This clause requires
contractors to obtain contracting officer
approval of the machinery, equipment,
material, or articles to be incorporated
into the work. The contractor’s request
must include: the manufacturer’s name,
the model number, and other
information concerning the
performance, capacity, nature, and
rating of the machinery and mechanical
and other equipment; and full
information concerning the material or
articles. When directed by the
contracting officer, the contractor must
submit samples of the items requiring
approval for incorporating into the
work. The contracting officer uses this
information to determine whether the
machinery, equipment, material, or
articles meet the standards of quality
specified in the contract. A contracting
officer may reject work, if the contractor
installs machinery, equipment, material,
or articles in the work without obtaining
the contracting officer’s approval.
• FAR 52.236–13, Accident
Prevention, Alternate I. This alternate to
the basic clause requires contractors to
submit a written proposed plan to
provide and maintain work
environments and procedures that will
safeguard the public and Government
personnel, property, materials, supplies,
and equipment exposed to contractor
operations and activities; avoid
interruptions of Government operations
and delays in project completion dates;
and control costs in the performance of
this contract. The plan must include an
analysis of the significant hazards to
life, limb, and property inherent in
E:\FR\FM\11MRN1.SGM
11MRN1
17470
Federal Register / Vol. 89, No. 48 / Monday, March 11, 2024 / Notices
contract work performance and a plan
for controlling these hazards. The
contracting officer and technical
representatives analyze the Accident
Prevention Plan to determine if the
proposed plan will satisfy the safety
requirements identified in the contract,
to include certain provisions of the
Occupational Safety and Health Act (per
FAR 36.513(c)) and applicable standards
issued by the Secretary of Labor at 29
CFR part 1926 and 29 CFR part 1910.
• FAR 52.236–15, Schedules for
Construction Contracts. This clause
requires contractors to prepare and
submit to the contracting officer for
approval three copies of a practicable
schedule showing the order in which
the contractor proposes to perform the
work, and the dates on which the
contractor contemplates starting and
completing the several salient features
of the work (including acquiring
materials, plant, and equipment). The
contracting officer uses this information
to monitor progress under a Federal
construction contract when other
management approaches for ensuring
adequate progress are not used.
• FAR 52.236–19, Organization and
Direction of the Work. This clause
requires contractors, under costreimbursement construction contracts,
to submit to the contracting officer a
chart showing the general executive and
administrative organization, the
personnel to be employed in connection
with the work under the contract, and
their respective duties. The contractor
must keep the data furnished current by
supplementing it as additional
information becomes available. The
contracting officer uses this information
to ensure the work is performed by
qualified personnel at a reasonable cost
to the Government.
C. Annual Burden
Respondents: 3,771.
Total Annual Responses: 13,267.
Total Burden Hours: 21,338.
ddrumheller on DSK120RN23PROD with NOTICES1
D. Public Comment
A 60-day notice was published in the
Federal Register at 89 FR 786, on
January 5, 2024. No comments were
received.
Obtaining Copies: Requesters may
obtain a copy of the information
collection documents from the GSA
Regulatory Secretariat Division, by
calling 202–501–4755 or emailing
GSARegSec@gsa.gov. Please cite OMB
Control No. 9000–0064, Certain Federal
VerDate Sep<11>2014
18:24 Mar 08, 2024
Jkt 262001
Acquisition Regulation Part 36
Construction Contract Requirements.
Janet Fry,
Director, Federal Acquisition Policy Division,
Office of Governmentwide Acquisition Policy,
Office of Acquisition Policy, Office of
Governmentwide Policy.
[FR Doc. 2024–05107 Filed 3–8–24; 8:45 am]
BILLING CODE 6820–EP–P
OFFICE OF GOVERNMENT ETHICS
Privacy Act of 1974; Systems of
Records
AGENCY:
Office of Government Ethics
(OGE).
ACTION:
Notice of a modified system of
records.
OGE proposes to revise an
existing Governmentwide system of
records under the Privacy Act, covering
Executive Branch Personnel Public
Financial Disclosure Reports and Other
Name-Retrieved Ethics Program
Records.
DATES: This action will be effective
without further notice on March 11,
2024 subject to a 30-day period in
which to comment on the new and
revised routine uses, described below.
Please submit any comments by April
10, 2024.
ADDRESSES: Comments may be
submitted to OGE by any of the
following methods:
Email: usoge@oge.gov (Include
reference to ‘‘OGE/GOVT–1’’ in the
subject line of the message.)
Mail, Hand Delivery/Courier: Office of
Government Ethics, Suite 750, 250 E
Street SW, Washington, DC 20024,
Attention: Jennifer Matis, Associate
Counsel.
Instructions: Comments may be
posted on OGE’s website, www.oge.gov.
Sensitive personal information, such as
account numbers or Social Security
numbers, should not be included.
Comments generally will not be edited
to remove any identifying or contact
information before posting.
FOR FURTHER INFORMATION CONTACT:
Jennifer Matis at the U.S. Office of
Government Ethics; telephone: 202–
482–9216; TTY: 800–877–8339; Email:
jmatis@oge.gov.
SUPPLEMENTARY INFORMATION: In
accordance with the Privacy Act of
1974, 5 U.S.C. 552a, this document
provides public notice that OGE is
proposing to revise the OGE/GOVT–1
Governmentwide system of records to
add a routine use to permit OGE to post
on its website information regarding
individuals who have filed a public
SUMMARY:
PO 00000
Frm 00099
Fmt 4703
Sfmt 4703
financial disclosure report pursuant to 5
U.S.C. 13103 and individuals who have
received a conflict of interest waiver
pursuant to 18 U.S.C. 208 (‘‘conflict of
interest waivers’’). OGE also plans to
update citations to the Ethics in
Government Act, update its street
address, clarify language in routine use
‘‘n,’’ and fix several typographical
errors. A Governmentwide system of
records is a system of records where one
agency (in this case, OGE) has
regulatory authority over records in the
custody of multiple agencies and the
agency with regulatory authority
publishes a system of records notice that
applies to all of the records regardless
of their custodial location.
Through the process described in 5
U.S.C. 13107, members of the public
may obtain both public financial
disclosure reports and conflict of
interest waivers from agencies
authorized to release those documents.
See 5 U.S.C. 13107, 18 U.S.C. 208(d)(1).
Although conflict of interest waivers
may already be requested from the
waiver recipient’s employing agency
using this process, currently the public
has no way to know who has received
a waiver in order to submit such a
request. Therefore, OGE is proposing to
add the waiver recipient’s first and last
name, government position, the type of
report filed or waiver issued, and name
of the employing agency to OGE’s
website, specifically its Officials’
Individual Disclosures Search
Collection (‘‘search collection’’).
Although OGE does not and will not
release conflict of interest waivers
issued by another agency, the posting of
this information on the OGE website
will make it easier for the waivers to be
requested from the waiver recipient’s
employing agency and help effectuate
the purposes of the statutory
transparency provisions. Accordingly,
OGE proposes to add a new routine use
‘‘c’’ to this system of records to permit
the disclosure.
The proposed routine use would also
explicitly permit the disclosure of
similar information regarding public
financial disclosure filers. In order to
allow users to select the documents they
wish to request, OGE’s search collection
currently displays the filer’s first and
last name, government position, the
type of report available, and name of the
employing agency. OGE has the
authority to display this information
pursuant to current routine use ‘‘a.’’
However, the language of routine use
‘‘a’’ does not make it plain to the public
that certain information regarding
public financial disclosure filers will be
posted on OGE’s website. Therefore,
OGE proposes to make that fact clear by
E:\FR\FM\11MRN1.SGM
11MRN1
]]>Agencies
[Federal Register Volume 89, Number 48 (Monday, March 11, 2024)]
[Notices]
[Pages 17469-17470]
From the Federal Register Online via the Government Publishing Office [www.gpo.gov]
[FR Doc No: 2024-05107]
=======================================================================
-----------------------------------------------------------------------
DEPARTMENT OF DEFENSE
GENERAL SERVICES ADMINISTRATION
NATIONAL AERONAUTICS AND SPACE ADMINISTRATION
[OMB Control No. 9000-0064; Docket No. 2024-0053; Sequence No. 1]
Submission for OMB Review; Certain Federal Acquisition Regulation
Part 36 Construction Contract Requirements
AGENCY: Department of Defense (DOD), General Services Administration
(GSA), and National Aeronautics and Space Administration (NASA).
ACTION: Notice.
-----------------------------------------------------------------------
SUMMARY: Under the provisions of the Paperwork Reduction Act, the
Regulatory Secretariat Division has submitted to the Office of
Management and Budget (OMB) a request to review and approve a revision
of a previously approved information collection requirement regarding
certain Federal Acquisition Regulation (FAR) part 36 construction
contract requirements.
DATES: Submit comments on or before April 10, 2024.
ADDRESSES: Written comments and recommendations for this information
collection should be sent within 30 days of publication of this notice
to www.reginfo.gov/public/do/PRAMain. Find this particular information
collection by selecting ``Currently under Review--Open for Public
Comments'' or by using the search function.
FOR FURTHER INFORMATION CONTACT: Zenaida Delgado, Procurement Analyst,
at telephone 202-969-7207, or [email protected].
SUPPLEMENTARY INFORMATION:
A. OMB Control Number, Title, and Any Associated Form(s)
9000-0064, Certain Federal Acquisition Regulation Part 36
Construction Contract Requirements.
B. Need and Uses
DoD, GSA, and NASA are combining OMB Control Nos. by FAR part. This
consolidation is expected to improve industry's ability to easily and
efficiently identify burdens associated with a given FAR part. This
review of the information collections by FAR part allows improved
oversight to ensure there is no redundant or unaccounted for burden
placed on industry. Lastly, combining information collections in a
given FAR part is also expected to reduce the administrative burden
associated with processing multiple information collections.
This justification supports the extension of OMB Control No. 9000-
0064 and combines it with the previously approved information
collection under OMB Control No. 9000-0062, with the new title
``Certain Federal Acquisition Regulation Part 36 Construction Contract
Requirements''. Upon approval of this consolidated information
collection, OMB Control No. 9000-0062 will be discontinued. The burden
requirements previously approved under the discontinued number will be
covered under OMB Control No. 9000-0064.
This clearance covers the information that contractors must submit
to comply with the following FAR requirements:
FAR 52.236-5, Material and Workmanship. This clause
requires contractors to obtain contracting officer approval of the
machinery, equipment, material, or articles to be incorporated into the
work. The contractor's request must include: the manufacturer's name,
the model number, and other information concerning the performance,
capacity, nature, and rating of the machinery and mechanical and other
equipment; and full information concerning the material or articles.
When directed by the contracting officer, the contractor must submit
samples of the items requiring approval for incorporating into the
work. The contracting officer uses this information to determine
whether the machinery, equipment, material, or articles meet the
standards of quality specified in the contract. A contracting officer
may reject work, if the contractor installs machinery, equipment,
material, or articles in the work without obtaining the contracting
officer's approval.
FAR 52.236-13, Accident Prevention, Alternate I. This
alternate to the basic clause requires contractors to submit a written
proposed plan to provide and maintain work environments and procedures
that will safeguard the public and Government personnel, property,
materials, supplies, and equipment exposed to contractor operations and
activities; avoid interruptions of Government operations and delays in
project completion dates; and control costs in the performance of this
contract. The plan must include an analysis of the significant hazards
to life, limb, and property inherent in
[[Page 17470]]
contract work performance and a plan for controlling these hazards. The
contracting officer and technical representatives analyze the Accident
Prevention Plan to determine if the proposed plan will satisfy the
safety requirements identified in the contract, to include certain
provisions of the Occupational Safety and Health Act (per FAR
36.513(c)) and applicable standards issued by the Secretary of Labor at
29 CFR part 1926 and 29 CFR part 1910.
FAR 52.236-15, Schedules for Construction Contracts. This
clause requires contractors to prepare and submit to the contracting
officer for approval three copies of a practicable schedule showing the
order in which the contractor proposes to perform the work, and the
dates on which the contractor contemplates starting and completing the
several salient features of the work (including acquiring materials,
plant, and equipment). The contracting officer uses this information to
monitor progress under a Federal construction contract when other
management approaches for ensuring adequate progress are not used.
FAR 52.236-19, Organization and Direction of the Work.
This clause requires contractors, under cost-reimbursement construction
contracts, to submit to the contracting officer a chart showing the
general executive and administrative organization, the personnel to be
employed in connection with the work under the contract, and their
respective duties. The contractor must keep the data furnished current
by supplementing it as additional information becomes available. The
contracting officer uses this information to ensure the work is
performed by qualified personnel at a reasonable cost to the
Government.
C. Annual Burden
Respondents: 3,771.
Total Annual Responses: 13,267.
Total Burden Hours: 21,338.
D. Public Comment
A 60-day notice was published in the Federal Register at 89 FR 786,
on January 5, 2024. No comments were received.
Obtaining Copies: Requesters may obtain a copy of the information
collection documents from the GSA Regulatory Secretariat Division, by
calling 202-501-4755 or emailing [email protected]. Please cite OMB
Control No. 9000-0064, Certain Federal Acquisition Regulation Part 36
Construction Contract Requirements.
Janet Fry,
Director, Federal Acquisition Policy Division, Office of Governmentwide
Acquisition Policy, Office of Acquisition Policy, Office of
Governmentwide Policy.
[FR Doc. 2024-05107 Filed 3-8-24; 8:45 am]
BILLING CODE 6820-EP-P
