Submission for OMB Review; Accident Prevention Plans and Recordkeeping, 22603-22604 [2016-08870]

Download as PDF Federal Register / Vol. 81, No. 74 / Monday, April 18, 2016 / Notices of this collection of information, including suggestions for reducing this burden to: Office of Information and Regulatory Affairs of OMB, Attention: Desk Officer for GSA, Room 10236, NEOB, Washington, DC 20503. Additionally submit a copy to GSA by any of the following methods: • Regulations.gov: http:// www.regulations.gov. Submit comments via the Federal eRulemaking portal by searching the OMB control number. Select the link ‘‘Submit a Comment’’ that corresponds with ‘‘Information Collection 9000–0175, Use of Project Labor Agreements for Federal Construction Projects’’. Follow the instructions provided at the ‘‘Submit a Comment’’ screen. Please include your name, company name (if any), and ‘‘Information Collection 9000–0175, Use of Project Labor Agreements for Federal Construction Projects’’ on your attached document. • Mail: General Services Administration, Regulatory Secretariat Division (MVCB), 1800 F Street NW., Washington, DC 20405. ATTN: Ms. Flowers/IC 9000–0175, Use of Project Labor Agreements for Federal Construction Projects. Instructions: Please submit comments only and cite Information Collection 9000–0175, Use of Project Labor Agreements for Federal Construction Projects, in all correspondence related to this collection. Comments received generally will be posted without change to http://www.regulations.gov, including any personal and/or business confidential information provided. To confirm receipt of your comment(s), please check www.regulations.gov, approximately two to three days after submission to verify posting (except allow 30 days for posting of comments submitted by mail). FOR FURTHER INFORMATION CONTACT: Mr. Edward Loeb, Procurement Analyst, Office of Governmentwide Acquisition Policy, at telephone 202–501–0650 or via email to edward.loeb@gsa.gov. SUPPLEMENTARY INFORMATION: mstockstill on DSK4VPTVN1PROD with NOTICES A. Purpose FAR 22.501 prescribes policies and procedures to implement Executive Order 13502, February 6, 2009 which encourages Federal agencies to consider the use of a project labor agreement (PLA), as they may decide appropriate, on large-scale construction projects, where the total cost to the Government is more than $25 million, in order to promote economy and efficiency in Federal procurement. A PLA is a prehire collective bargaining agreement with one or more labor organizations VerDate Sep<11>2014 17:54 Apr 15, 2016 Jkt 238001 that establishes the terms and conditions of employment for a specific construction project. FAR 22.503(b) provides that an agency may, if appropriate, require that every contractor and subcontractor engaged in construction on the project agree, for that project, to negotiate or become a party to a project labor agreement with one or more labor organizations if the agency decides that the use of project labor agreements will— (1) Advance the Federal Government’s interest in achieving economy and efficiency in Federal procurement, producing labor-management stability, and ensuring compliance with laws and regulations governing safety and health, equal employment opportunity, labor and employment standards, and other matters; and, (2) Be consistent with law. B. Annual Reporting Burden Respondents: 70. Responses per Respondent: 1. Annual Responses: 70. Hours per Response: 1. Total Burden Hours: 70. C. Public Comments Public comments are particularly invited on: Whether this collection of information is necessary for the proper performance of functions of the FAR, and whether it will have practical utility; whether our estimate of the public burden of this collection of information is accurate, and based on valid assumptions and methodology; ways to enhance the quality, utility, and clarity of the information to be collected; and ways in which we can minimize the burden of the collection of information on those who are to respond, through the use of appropriate technological collection techniques or other forms of information technology. Obtaining Copies of Proposals: Requesters may obtain a copy of the information collection documents from the General Services Administration, Regulatory Secretariat Division (MVCB), 1800 F Street NW., Washington, DC 20405, telephone 202–501–4755. Please cite OMB Control No. 9000–0175, Use of Project Labor Agreements for Federal Construction Projects, in all correspondence. Dated: April 13, 2016. Lorin S. Curit, Director, Federal Acquisition Policy Division, Office of Governmentwide Acquisition Policy, Office of Acquisition Policy, Office of Governmentwide Policy. [FR Doc. 2016–08873 Filed 4–15–16; 8:45 am] BILLING CODE 6820–EP–P PO 00000 Frm 00037 Fmt 4703 Sfmt 4703 22603 DEPARTMENT OF DEFENSE GENERAL SERVICES ADMINISTRATION NATIONAL AERONAUTICS AND SPACE ADMINISTRATION [OMB Control No. 9000–0060; Docket 2016– 0053; Sequence 5] Submission for OMB Review; Accident Prevention Plans and Recordkeeping Department of Defense (DOD), General Services Administration (GSA), and National Aeronautics and Space Administration (NASA). ACTION: Notice of request for an extension of an information collection requirement regarding an existing OMB clearance. AGENCY: Under the provisions of the Paperwork Reduction Act, Regulatory Secretariat Division will be submitting to the Office of Management and Budget (OMB) a request to review and approve an extension of a previously approved information collection requirement concerning Accident Prevention Plans and Recordkeeping. A notice published in the Federal Register at 81 FR 6517 on February 8, 2016. No comments were received. SUMMARY: Submit comments on or before May 18, 2016. ADDRESSES: Submit comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden to: Office of Information and Regulatory Affairs of OMB, Attention: Desk Officer for GSA, Room 10236, NEOB, Washington, DC 20503. Additionally submit a copy to GSA by any of the following methods: • Regulations.gov: http:// www.regulations.gov. Submit comments via the Federal eRulemaking portal by searching for Information Collection 9000–0060, Accident Prevention Plans and Recordkeeping. Select the link ‘‘Comment Now’’ that corresponds with ‘‘Information Collection 9000–0060, Accident Prevention Plans and Recordkeeping’’. Follow the instructions provided on the screen. Please include your name, company name (if any), and ‘‘Information Collection 9000–0060, Accident Prevention Plans and Recordkeeping’’ on your attached document. • Mail: General Services Administration, Regulatory Secretariat Division (MVCB), 1800 F Street NW., Washington, DC 20405. ATTN: Ms. Flowers/IC 9000–0060, Accident Prevention Plans and Recordkeeping. DATES: E:\FR\FM\18APN1.SGM 18APN1 22604 Federal Register / Vol. 81, No. 74 / Monday, April 18, 2016 / Notices Instructions: Please submit comments only and cite Information Collection 9000–0060, Accident Prevention Plans and Recordkeeping, in all correspondence related to this collection. Comments received generally will be posted without change to http://www.regulations.gov, including any personal and/or business confidential information provided. To confirm receipt of your comment(s), please check www.regulations.gov, approximately two to three days after submission to verify posting (except allow 30 days for posting of comments submitted by mail). FOR FURTHER INFORMATION CONTACT: Mr. Curtis E. Glover, Sr., Procurement Analyst, Contract Policy Division, GSA, telephone 202–501–1448 or email at curtis.glover@gsa.gov. SUPPLEMENTARY INFORMATION: mstockstill on DSK4VPTVN1PROD with NOTICES A. Purpose The FAR clause at 52.236–13, Accident Prevention, requires Federal construction contractors to keep records of accidents incident to work performed under the contract that result in death, traumatic injury, occupational disease or damage to property, materials, supplies or equipment. Records of personal inquiries are required by the Department of Labor’s (DOL) Occupational Safety and Health Administration regulations (OSHA). The records maintained by the contractor are used to evaluate compliance and may be used in workmen’s compensation cases. The Federal Acquisition Regulation (FAR) requires records of damage to property, materials, supplies or equipment to provide background information when claims are brought against the Government. If the contract involves work of a long duration, or hazardous nature, the contracting officer shall insert the clause with its alternate that requires the contractor to submit a written proposed plan for implementing the clause. The plan shall include an analysis of the significant hazards to life, limb, and property inherent in performing the contract and a plan for controlling the hazards. The Accident Prevention Plan (APP) is analyzed by the contracting officer along with the agency safety representatives to determine if the proposed plan will meet the requirements of safety regulations and applicable statutes. B. Annual Reporting Burden Respondents: 215. Responses per Respondent: 1. Annual Responses: 215. Hours per Response: 22. VerDate Sep<11>2014 17:54 Apr 15, 2016 Jkt 238001 Total Burden Hours: 4,730 Department of Defense (DOD), General Services Administration (GSA), and National Aeronautics and Space Administration (NASA). ACTION: Notice of request for public comments regarding an extension to an existing OMB clearance. database. A notice was published in the Federal Register at 81 FR 6515 on February 8, 2016. No comments were received. DATES: Submit comments on or before May 18, 2016. ADDRESSES: Submit comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden to: Office of Information and Regulatory Affairs of OMB, Attention: Desk Officer for GSA, Room 10236, NEOB, Washington, DC 20503. Additionally submit a copy to GSA by any of the following methods: • Regulations.gov: http:// www.regulations.gov. Submit comments via the Federal eRulemaking portal by searching for the OMB control number. Select the link ‘‘Submit a Comment’’ that corresponds with ‘‘Information Collection 9000–0159, Central Contractor Registration.’’ Follow the instructions provided at the ‘‘Submit a Comment’’ screen. Please include your name, company name (if any), and ‘‘Information Collection 9000–0159, Central Contractor Registration’’ on your attached document. • Mail: General Services Administration, Regulatory Secretariat Division (MVCB), 1800 F Street NW., Washington, DC 20405. ATTN: Ms. Flowers/IC 9000–0159, Central Contractor Registration. Instructions: Please submit comments only and cite Information Collection 9000–0159, Central Contractor Registration, in all correspondence related to this collection. Comments received generally will be posted without change to http:// www.regulations.gov, including any personal and/or business confidential information provided. To confirm receipt of your comment(s), please check www.regulations.gov, approximately two to three days after submission to verify posting (except allow 30 days for posting of comments submitted by mail). FOR FURTHER INFORMATION CONTACT: Mr. Curtis E. Glover, Sr., Procurement Analyst, Office of Governmentwide Policy, GSA, 202–501–1448, or via email at curtis.glover@gsa.gov. SUPPLEMENTARY INFORMATION: Under the provisions of the Paperwork Reduction Act, the Regulatory Secretariat Division will be submitting to the Office of Management and Budget (OMB) a request to review and approve an extension of a previously approved information collection requirement concerning the Central Contractor Registration A. Purpose The Federal Acquisition Regulation (FAR) Subpart 4.11 prescribes policies and procedures for requiring contractor registration in the Central Contractor Registration (CCR) database. The CCR is the primary vendor database for the U.S. Federal Government. CCR collects, validates, stores, and disseminates data C. Public Comments Public comments are particularly invited on: Whether this collection of information is necessary; whether it will have practical utility; whether our estimate of the public burden of this collection of information is accurate, and based on valid assumptions and methodology; ways to enhance the quality, utility, and clarity of the information to be collected; and ways in which we can minimize the burden of the collection of information on those who are to respond, through the use of appropriate technological collection techniques or other forms of information technology. Obtaining Copies of Proposals: Requesters may obtain a copy of the information collection documents from the General Services Administration, Regulatory Secretariat Division (MVCB), 1800 F Street NW., Washington, DC 20405, telephone 202–501–4755. Please cite OMB Control No. 9000–0060, Accident Prevention Plans and Recordkeeping, in all correspondence. Dated: April 13, 2016. Lorin S. Curit, Director, Federal Acquisition Policy Division, Office of Governmentwide Acquisition Policy, Office of Acquisition Policy, Office of Governmentwide Policy. [FR Doc. 2016–08870 Filed 4–15–16; 8:45 am] BILLING CODE 6820–EP–P DEPARTMENT OF DEFENSE GENERAL SERVICES ADMINISTRATION NATIONAL AERONAUTICS AND SPACE ADMINISTRATION [OMB Control No. 9000–0159; Docket 2016– 0053; Sequence 4] Submission for OMB Review; Central Contractor Registration AGENCY: SUMMARY: PO 00000 Frm 00038 Fmt 4703 Sfmt 4703 E:\FR\FM\18APN1.SGM 18APN1

Agencies

[Federal Register Volume 81, Number 74 (Monday, April 18, 2016)]
[Notices]
[Pages 22603-22604]
From the Federal Register Online via the Government Publishing Office [www.gpo.gov]
[FR Doc No: 2016-08870]


-----------------------------------------------------------------------

DEPARTMENT OF DEFENSE

GENERAL SERVICES ADMINISTRATION

NATIONAL AERONAUTICS AND SPACE ADMINISTRATION

[OMB Control No. 9000-0060; Docket 2016-0053; Sequence 5]


Submission for OMB Review; Accident Prevention Plans and 
Recordkeeping

AGENCY: Department of Defense (DOD), General Services Administration 
(GSA), and National Aeronautics and Space Administration (NASA).

ACTION: Notice of request for an extension of an information collection 
requirement regarding an existing OMB clearance.

-----------------------------------------------------------------------

SUMMARY: Under the provisions of the Paperwork Reduction Act, 
Regulatory Secretariat Division will be submitting to the Office of 
Management and Budget (OMB) a request to review and approve an 
extension of a previously approved information collection requirement 
concerning Accident Prevention Plans and Recordkeeping. A notice 
published in the Federal Register at 81 FR 6517 on February 8, 2016. No 
comments were received.

DATES: Submit comments on or before May 18, 2016.

ADDRESSES: Submit comments regarding this burden estimate or any other 
aspect of this collection of information, including suggestions for 
reducing this burden to: Office of Information and Regulatory Affairs 
of OMB, Attention: Desk Officer for GSA, Room 10236, NEOB, Washington, 
DC 20503. Additionally submit a copy to GSA by any of the following 
methods:
     Regulations.gov: http://www.regulations.gov. Submit 
comments via the Federal eRulemaking portal by searching for 
Information Collection 9000-0060, Accident Prevention Plans and 
Recordkeeping. Select the link ``Comment Now'' that corresponds with 
``Information Collection 9000-0060, Accident Prevention Plans and 
Recordkeeping''. Follow the instructions provided on the screen. Please 
include your name, company name (if any), and ``Information Collection 
9000-0060, Accident Prevention Plans and Recordkeeping'' on your 
attached document.
     Mail: General Services Administration, Regulatory 
Secretariat Division (MVCB), 1800 F Street NW., Washington, DC 20405. 
ATTN: Ms. Flowers/IC 9000-0060, Accident Prevention Plans and 
Recordkeeping.

[[Page 22604]]

    Instructions: Please submit comments only and cite Information 
Collection 9000-0060, Accident Prevention Plans and Recordkeeping, in 
all correspondence related to this collection. Comments received 
generally will be posted without change to http://www.regulations.gov, 
including any personal and/or business confidential information 
provided. To confirm receipt of your comment(s), please check 
www.regulations.gov, approximately two to three days after submission 
to verify posting (except allow 30 days for posting of comments 
submitted by mail).

FOR FURTHER INFORMATION CONTACT: Mr. Curtis E. Glover, Sr., Procurement 
Analyst, Contract Policy Division, GSA, telephone 202-501-1448 or email 
at curtis.glover@gsa.gov.

SUPPLEMENTARY INFORMATION:

A. Purpose

    The FAR clause at 52.236-13, Accident Prevention, requires Federal 
construction contractors to keep records of accidents incident to work 
performed under the contract that result in death, traumatic injury, 
occupational disease or damage to property, materials, supplies or 
equipment. Records of personal inquiries are required by the Department 
of Labor's (DOL) Occupational Safety and Health Administration 
regulations (OSHA). The records maintained by the contractor are used 
to evaluate compliance and may be used in workmen's compensation cases. 
The Federal Acquisition Regulation (FAR) requires records of damage to 
property, materials, supplies or equipment to provide background 
information when claims are brought against the Government.
    If the contract involves work of a long duration, or hazardous 
nature, the contracting officer shall insert the clause with its 
alternate that requires the contractor to submit a written proposed 
plan for implementing the clause. The plan shall include an analysis of 
the significant hazards to life, limb, and property inherent in 
performing the contract and a plan for controlling the hazards. The 
Accident Prevention Plan (APP) is analyzed by the contracting officer 
along with the agency safety representatives to determine if the 
proposed plan will meet the requirements of safety regulations and 
applicable statutes.

B. Annual Reporting Burden

    Respondents: 215.
    Responses per Respondent: 1.
    Annual Responses: 215.
    Hours per Response: 22.
    Total Burden Hours: 4,730

C. Public Comments

    Public comments are particularly invited on: Whether this 
collection of information is necessary; whether it will have practical 
utility; whether our estimate of the public burden of this collection 
of information is accurate, and based on valid assumptions and 
methodology; ways to enhance the quality, utility, and clarity of the 
information to be collected; and ways in which we can minimize the 
burden of the collection of information on those who are to respond, 
through the use of appropriate technological collection techniques or 
other forms of information technology.
    Obtaining Copies of Proposals: Requesters may obtain a copy of the 
information collection documents from the General Services 
Administration, Regulatory Secretariat Division (MVCB), 1800 F Street 
NW., Washington, DC 20405, telephone 202-501-4755. Please cite OMB 
Control No. 9000-0060, Accident Prevention Plans and Recordkeeping, in 
all correspondence.

    Dated: April 13, 2016.
Lorin S. Curit,
Director, Federal Acquisition Policy Division, Office of Governmentwide 
Acquisition Policy, Office of Acquisition Policy, Office of 
Governmentwide Policy.
[FR Doc. 2016-08870 Filed 4-15-16; 8:45 am]
 BILLING CODE 6820-EP-P