Notice of Proposed Information Collection: Comment Request; Multifamily Project Construction Contract, Building Loan Agreement, and Construction Change Request, 21617-21618 [2013-08516]

Download as PDF Federal Register / Vol. 78, No. 70 / Thursday, April 11, 2013 / Notices 93.846–93.878, 93.892, 93.893, National Institutes of Health, HHS) DEPARTMENT OF HOUSING AND URBAN DEVELOPMENT Dated: April 5, 2013. Carolyn A. Baum, Program Analyst, Office of Federal Advisory Committee Policy. [Docket No. FR–5687–N–18] [FR Doc. 2013–08417 Filed 4–10–13; 8:45 am] Notice of Proposed Information Collection: Comment Request; Final Endorsement of Credit Instrument BILLING CODE 4140–01–P AGENCY: DEPARTMENT OF HEALTH AND HUMAN SERVICES SUMMARY: Office of the Assistant Secretary for Housing, HUD. ACTION: Notice. National Institutes of Health National Institute of Arthritis and Musculoskeletal and Skin Diseases; Notice of Closed Meeting TKELLEY on DSK3SPTVN1PROD with NOTICES Pursuant to section 10(d) of the Federal Advisory Committee Act, as amended (5 U.S.C. App.), notice is hereby given of the following meeting. The meeting will be closed to the public in accordance with the provisions set forth in sections 552b(c)(4) and 552b(c)(6), Title 5 U.S.C., as amended. The grant applications and the discussions could disclose confidential trade secrets or commercial property such as patentable material, and personal information concerning individuals associated with the grant applications, the disclosure of which would constitute a clearly unwarranted invasion of personal privacy. Name of Committee: National Institute of Arthritis and Musculoskeletal and Skin Diseases Special Emphasis Panel, NIAMS Small Grant Program for New Investigators (R03). Date: April 25, 2013. Time: 9:00 a.m. to 7:00 p.m. Agenda: To review and evaluate. grant applications. Place: National Institutes of Health, 6701 Democracy Boulevard, Suite 824, Bethesda, MD 20892, (Virtual Meeting). Contact Person: Eric H. Brown, MS, Ph.D., Scientific Review Officer, Scientific Review Branch, National Institute of Arthritis, Musculoskeletal and Skin Diseases, NIH, 6701 Democracy Boulevard, Suite 800, Bethesda, MD 20892, (301) 594–4955, browneri@mail.nih.gov. (Catalogue of Federal Domestic Assistance Program Nos. 93.846, Arthritis, Musculoskeletal and Skin Diseases Research, National Institutes of Health, HHS) Dated: April 5, 2013. Carolyn A. Baum, Program Analyst, Office of Federal Advisory Committee Policy. [FR Doc. 2013–08420 Filed 4–10–13; 8:45 am] BILLING CODE 4140–01–P VerDate Mar<15>2010 17:37 Apr 10, 2013 Jkt 229001 The proposed information collection requirement described below will be submitted to the Office of Management and Budget (OMB) for review, as required by the Paperwork Reduction Act. The Department is soliciting public comments on the subject proposal. DATES: Comments Due Date: June 10, 2013. ADDRESSES: Interested persons are invited to submit comments regarding this proposal. Comments should refer to the proposal by name and/or OMB Control Number and should be sent to: Reports Liaison Officer, Department of Housing and Urban Development, 451 7th Street SW., Washington, DC 20410, Room 9120 or the number for the Federal Information Relay Service (1–800–877–8339). FOR FURTHER INFORMATION CONTACT: Theodore K. Toon, Director, Office of Multifamily Housing Development, Department of Housing and Urban Development, 451 7th Street SW., Washington, DC 20410, telephone (202) 708–1142 (this is not a toll free number) for copies of the proposed forms and other available information. SUPPLEMENTARY INFORMATION: The Department is submitting the proposed information collection to OMB for review, as required by the Paperwork Reduction Act of 1995 (44 U.S.C. chapter 35, as amended). This Notice is soliciting comments from members of the public and affected agencies concerning the proposed collection of information to: (1) Evaluate whether the proposed collection is necessary for the proper performance of the functions of the agency, including whether the information will have practical utility; (2) Evaluate the accuracy of the agency’s estimate of the burden of the proposed collection of information; (3) Enhance the quality, utility, and clarity of the information to be collected; and (4) Minimize the burden of the collection of information on those who are to respond; including the use of appropriate automated collection techniques or other forms of information technology, e.g., permitting electronic submission of responses. PO 00000 Frm 00028 Fmt 4703 Sfmt 4703 21617 This Notice also lists the following information: Title of Proposal: Final Endorsement of Credit Instrument. OMB Control Number, if applicable: 2502–0016. Description of the need for the information and proposed use: The information collected on the ‘‘Final Endorsement of Credit Instrument’’ form is used to request to request final endorsement by HUD of the credit instrument. The mortgagee/lender submits information to indicate the schedule of advances made on the project and the final advances to be disbursed immediately upon final endorsement. Agency form numbers, if applicable: HUD–92023. Estimation of the total numbers of hours needed to prepare the information collection including number of respondents, frequency of response, and hours of response: The number of burden hours is 5,126. The number of respondents is 5,126, the number of responses is 5,126, the frequency of response is on occasion, and the burden hour per response is 1 hr. Status of the proposed information collection: This is a revision without change of a currently approved collection. Authority: The Paperwork Reduction Act of 1995, 44 U.S.C., Chapter 35, as amended. Dated: April 8, 2013. Laura M. Marin, Acting General Deputy Assistant Secretary for Housing-Acting General Deputy Federal Housing Commissioner. [FR Doc. 2013–08515 Filed 4–10–13; 8:45 am] BILLING CODE 4210–67–P DEPARTMENT OF HOUSING AND URBAN DEVELOPMENT [Docket No. FR–5687–N–19] Notice of Proposed Information Collection: Comment Request; Multifamily Project Construction Contract, Building Loan Agreement, and Construction Change Request Office of the Assistant Secretary for Housing, HUD. ACTION: Notice. AGENCY: The proposed information collection requirement described below will be submitted to the Office of Management and Budget (OMB) for review, as required by the Paperwork Reduction Act. The Department is soliciting public comments on the subject proposal. DATES: Comments Due Date: June 10, 2013. SUMMARY: E:\FR\FM\11APN1.SGM 11APN1 21618 Federal Register / Vol. 78, No. 70 / Thursday, April 11, 2013 / Notices Interested persons are invited to submit comments regarding this proposal. Comments should refer to the proposal by name and/or OMB Control Number and should be sent to: Reports Liaison Officer, Department of Housing and Urban Development, 451 7th Street SW., Washington, DC 20410, Room 9120 or the number for the Federal Relay information Service, 1–800–877–8330. FOR FURTHER INFORMATION CONTACT: Theodore K. Toon, Director, Office of Multifamily Housing Development, Department of Housing and Urban Development, 451 7th Street SW., Washington, DC 20410, telephone (202) 402–8386 (this is not a toll free number) for copies of the proposed forms and other available information. SUPPLEMENTARY INFORMATION: The Department is submitting the proposed information collection to OMB for review, as required by the Paperwork Reduction Act of 1995 (44 U.S.C. chapter 35, as amended). This Notice is soliciting comments from members of the public and affected agencies concerning the proposed collection of information to: (1) Evaluate whether the proposed collection is necessary for the proper performance of the functions of the agency, including whether the information will have practical utility; (2) Evaluate the accuracy of the agency’s estimate of the burden of the proposed collection of information; (3) Enhance the quality, utility, and clarity of the information to be collected; and (4) Minimize the burden of the collection of information on those who are to respond; including the use of appropriate automated collection techniques or other forms of information technology, e.g., permitting electronic submission of responses. This Notice also lists the following information: Title of Proposal: Multifamily Project Construction Contract, Building Loan Agreement, and Construction Change Request. OMB Control Number, if applicable: 2502–0011. Description of the need for the information and proposed use: The information collected on the ‘‘Multifamily Project Construction Contract, Building Loan Agreement, and Construction Change Request’’ form provides HUD with information from contractors, mortgagors/borrowers, and mortgagees/lenders for construction of multifamily projects and to obtain approval of changes in previously approved contract drawings and/or specifications. TKELLEY on DSK3SPTVN1PROD with NOTICES ADDRESSES: VerDate Mar<15>2010 17:37 Apr 10, 2013 Jkt 229001 Agency form numbers, if applicable: HUD–92437, HUD–92441, HUD–92442, HUD–92442–A, HUD–92442–CA and HUD–92442–A–CA. Estimation of the total numbers of hours needed to prepare the information collection including number of respondents, frequency of response, and hours of response: The number of burden hours is 9538. The number of respondents is 1158, the number of responses is 1158, the frequency of response is annually, and the burden hour per response is 3 hours. Status of the proposed information collection: This is an extension of a currently approved collection. Authority: The Paperwork Reduction Act of 1995, 44 U.S.C., Chapter 35, as amended. Dated: April 8, 2013. Laura M. Marin, Acting General Deputy Assistant Secretary for Housing-Acting General Deputy Federal Housing Commissioner. [FR Doc. 2013–08516 Filed 4–10–13; 8:45 am] BILLING CODE 4210–67–P DEPARTMENT OF HOUSING AND URBAN DEVELOPMENT [Docket No. FR–5706–N–01] Mortgagee Review Board: Administrative Actions Office of the Assistant Secretary for Housing—Federal Housing Commissioner, Department of Housing and Urban Development (HUD). ACTION: Notice. AGENCY: In compliance with Section 202(c) (5) of the National Housing Act, this notice advises of the cause and description of administrative actions taken by HUD’s Mortgagee Review Board against HUD-approved mortgagees. FOR FURTHER INFORMATION CONTACT: Nancy A. Murray, Secretary to the Mortgagee Review Board, 451 Seventh Street SW., Room B–133/3150, Washington, DC 20410–8000; telephone number 202–708–2224 (this is not a tollfree number). Persons with hearing or speech impairments may access this number through TTY by calling the tollfree Federal Information Service at 800– 877–8339. SUPPLEMENTARY INFORMATION: Section 202(c)(5) of the National Housing Act (12 U.S.C. 1708(c)(5)) requires that HUD ‘‘publish a description of and the cause for administrative action against a HUDapproved mortgagee’’ by the Department’s Mortgagee Review Board (‘‘Board’’). In compliance with the requirements of Section 202(c)(5), this SUMMARY: PO 00000 Frm 00029 Fmt 4703 Sfmt 4703 notice advises of actions that have been taken by the Board in its meetings from January 1, 2012 to September 30, 2012. I. Civil Money Penalties, Withdrawals of FHA Approval, Suspensions, Probations, Reprimands, and Administrative Payments 1. Academy Mortgage Corporation, Sandy, UT [Docket No. 12–1609–MR] Action: On April 27, 2012, the Board entered into a Settlement Agreement with Academy Mortgage Corporation (Academy) that required Academy to pay a civil money penalty in the amount of $75,000, without admitting fault or liability. Cause: The Board took this action based on the following violations of HUD/FHA requirements alleged by HUD: Academy failed to notify the Department that it was the subject of multiple state regulatory actions and sanctions, and submitted false certifications to HUD in connection with Academy’s annual renewal of eligibility documentation for its fiscal years ending in 2009, 2010 and 2011. 2. AmericaHomeKey, Inc., Dallas, TX [Docket No. 11–1294–MR] Action: On March 22, 2012, the Board issued a Notice of Administrative Action immediately and permanently withdrawing the FHA approval of AmericaHomeKey, Inc. (AHK). Cause: The Board took this action based on the following violations of HUD/FHA requirements alleged by HUD: AHK failed to perform quality control functions in compliance with HUD/FHA requirements, failed to meet the requirements for participation in the FHA mortgage insurance program, failed to ensure the correct mortgagee identification number was used when originating FHA-insured mortgage loans, failed to adequately document the source of and/or adequacy of funds used for closing, failed to correctly calculate and document the mortgagor’s income, failed to verify the stability of the mortgagor’s income, failed to ensure the mortgagor was eligible for an FHAinsured mortgage loan, failed to ensure the property met HUD’s eligibility requirements, failed to comply with TOTAL Scorecard requirements, failed to comply with HUD’s property flipping requirements, failed to provide construction documents required for property eligibility and/or high ratio financing resulting in over-insured mortgages, failed to ensure that the maximum mortgage amount was correctly calculated, resulting in overinsured mortgages, failed to ensure that data submitted to HUD systems was E:\FR\FM\11APN1.SGM 11APN1

Agencies

[Federal Register Volume 78, Number 70 (Thursday, April 11, 2013)]
[Notices]
[Pages 21617-21618]
From the Federal Register Online via the Government Printing Office [www.gpo.gov]
[FR Doc No: 2013-08516]


-----------------------------------------------------------------------

DEPARTMENT OF HOUSING AND URBAN DEVELOPMENT

[Docket No. FR-5687-N-19]


Notice of Proposed Information Collection: Comment Request; 
Multifamily Project Construction Contract, Building Loan Agreement, and 
Construction Change Request

AGENCY: Office of the Assistant Secretary for Housing, HUD.

ACTION: Notice.

-----------------------------------------------------------------------

SUMMARY: The proposed information collection requirement described 
below will be submitted to the Office of Management and Budget (OMB) 
for review, as required by the Paperwork Reduction Act. The Department 
is soliciting public comments on the subject proposal.

DATES: Comments Due Date: June 10, 2013.

[[Page 21618]]


ADDRESSES: Interested persons are invited to submit comments regarding 
this proposal. Comments should refer to the proposal by name and/or OMB 
Control Number and should be sent to: Reports Liaison Officer, 
Department of Housing and Urban Development, 451 7th Street SW., 
Washington, DC 20410, Room 9120 or the number for the Federal Relay 
information Service, 1-800-877-8330.

FOR FURTHER INFORMATION CONTACT: Theodore K. Toon, Director, Office of 
Multifamily Housing Development, Department of Housing and Urban 
Development, 451 7th Street SW., Washington, DC 20410, telephone (202) 
402-8386 (this is not a toll free number) for copies of the proposed 
forms and other available information.

SUPPLEMENTARY INFORMATION: The Department is submitting the proposed 
information collection to OMB for review, as required by the Paperwork 
Reduction Act of 1995 (44 U.S.C. chapter 35, as amended).
    This Notice is soliciting comments from members of the public and 
affected agencies concerning the proposed collection of information to: 
(1) Evaluate whether the proposed collection is necessary for the 
proper performance of the functions of the agency, including whether 
the information will have practical utility; (2) Evaluate the accuracy 
of the agency's estimate of the burden of the proposed collection of 
information; (3) Enhance the quality, utility, and clarity of the 
information to be collected; and (4) Minimize the burden of the 
collection of information on those who are to respond; including the 
use of appropriate automated collection techniques or other forms of 
information technology, e.g., permitting electronic submission of 
responses. This Notice also lists the following information:
    Title of Proposal: Multifamily Project Construction Contract, 
Building Loan Agreement, and Construction Change Request.
    OMB Control Number, if applicable: 2502-0011.
    Description of the need for the information and proposed use: The 
information collected on the ``Multifamily Project Construction 
Contract, Building Loan Agreement, and Construction Change Request'' 
form provides HUD with information from contractors, mortgagors/
borrowers, and mortgagees/lenders for construction of multifamily 
projects and to obtain approval of changes in previously approved 
contract drawings and/or specifications.
    Agency form numbers, if applicable: HUD-92437, HUD-92441, HUD-
92442, HUD-92442-A, HUD-92442-CA and HUD-92442-A-CA.
    Estimation of the total numbers of hours needed to prepare the 
information collection including number of respondents, frequency of 
response, and hours of response: The number of burden hours is 9538. 
The number of respondents is 1158, the number of responses is 1158, the 
frequency of response is annually, and the burden hour per response is 
3 hours.
    Status of the proposed information collection: This is an extension 
of a currently approved collection.

    Authority: The Paperwork Reduction Act of 1995, 44 U.S.C., 
Chapter 35, as amended.

    Dated: April 8, 2013.
Laura M. Marin,
Acting General Deputy Assistant Secretary for Housing-Acting General 
Deputy Federal Housing Commissioner.
[FR Doc. 2013-08516 Filed 4-10-13; 8:45 am]
BILLING CODE 4210-67-P