Information Collection Requirement; Defense Federal Acquisition Regulation Supplement; Contract Administration and Audit Services (OMB Control Number 0704-0250), 39064-39065 [E9-18756]

Download as PDF 39064 Federal Register / Vol. 74, No. 149 / Wednesday, August 5, 2009 / Notices srobinson on DSKHWCL6B1PROD with NOTICES Atmospheric Administration (NOAA), Commerce. ACTION: Notice of public meeting. SUMMARY: NMFS will hold a 3–day Atlantic Highly Migratory Species (HMS) Advisory Panel (AP) meeting in September 2009. The intent of the meeting is to consider options for the conservation and management of Atlantic HMS. The meeting is open to the public. DATES: The AP meeting will be held from 1 p.m. to 5 p.m. on Wednesday, September 9, 2009, from 8 a.m. to 5 p.m. on Thursday, September 10, 2009, and from 8 a.m. to 2:30 p.m. on Friday, September 11, 2009. ADDRESSES: The meeting will be held in Silver Spring, MD 20910. FOR FURTHER INFORMATION CONTACT: Othel Freeman or Margo SchulzeHaugen at 301–713–2347. SUPPLEMENTARY INFORMATION: The Magnuson-Stevens Fishery Conservation and Management Act, 16 U.S.C. 1801 et seq., as amended by the Sustainable Fisheries Act, Public Law 104–297, provided for the establishment of an AP to assist in the collection and evaluation of information relevant to the development of any Fishery Management Plan (FMP) or FMP amendment for HMS. NMFS consults with and considers the comments and views of AP members when preparing and implementing FMPs or FMP amendments for Atlantic tunas, swordfish, billfish, and sharks. The AP has previously consulted with NMFS on: Amendment 1 to the Billfish FMP (April 1999), the HMS FMP (April 1999), Amendment 1 to the HMS FMP (December 2003), the Consolidated HMS FMP (October 2006), and Amendments 1, 2, and 3 to the Consolidated HMS FMP (April and October 2008, and February 2009). At the September 2009 AP meeting, NMFS plans to hold public hearings to discuss Amendments 3 and 4 to the 2006 Consolidated HMS FMP for small coastal sharks, and Caribbean fishery management measures, respectively, and for Atlantic bluefin tuna and swordfish based on an Advanced Notice of Proposed Rulemaking that published on June 1, 2009 (74 FR 26174). Other potential items for discussion include annual quota specifications for bluefin tuna, swordfish, and sharks, as well as the 2010 meeting of the International Commission for the Conservation of Atlantic Tunas. Special Accommodations This meeting is physically accessible to people with disabilities. Requests for VerDate Nov<24>2008 18:54 Aug 04, 2009 Jkt 217001 sign language interpretation or other auxiliary aids should be directed to Othel Freeman at (301) 713–2347, at least 7 days prior to the meeting. Dated: July 30, 2009. Kristen C. Koch, Acting Director, Office of Sustainable Fisheries, National Marine Fisheries Service. [FR Doc. E9–18749 Filed 8–4–09; 8:45 am] BILLING CODE 3510–22–S DEPARTMENT OF DEFENSE Defense Acquisition Regulations System Information Collection Requirement; Defense Federal Acquisition Regulation Supplement; Contract Administration and Audit Services (OMB Control Number 0704–0250) AGENCY: Defense Acquisition Regulations System, Department of Defense (DoD). ACTION: Notice and request for comments regarding a proposed extension of an approved information collection requirement. SUMMARY: In compliance with Section 3506(c)(2)(A) of the Paperwork Reduction Act of 1995 (44 U.S.C. Chapter 35), DoD announces the proposed extension of a public information collection requirement and seeks public comment on the provisions thereof. DoD invites comments on: (a) Whether the proposed collection of information is necessary for the proper performance of the functions of DoD, including whether the information will have practical utility; (b) the accuracy of the estimate of the burden of the proposed information collection; (c) ways to enhance the quality, utility, and clarity of the information to be collected; and (d) ways to minimize the burden of the information collection on respondents, including the use of automated collection techniques or other forms of information technology. The Office of Management and Budget (OMB) has approved this information collection for use through July 31, 2009. DoD proposes that OMB extend its approval for use for three additional years. DATES: DoD will consider all comments received by October 5, 2009. ADDRESSES: You may submit comments, identified by OMB Control Number 0704–0250, using any of the following methods: Æ Federal eRulemaking Portal: http://www.regulations.gov. Follow the instructions for submitting comments. PO 00000 Frm 00025 Fmt 4703 Sfmt 4703 Æ E-mail: dfars@osd.mil. Include OMB Control Number 0704–0250 in the subject line of the message. Æ Fax: 703–602–7887. Æ Mail: Defense Acquisition Regulations System, Attn: Mr. Mark Gomersall, OUSD(AT&L)DPAP(DARS), IMD 3D139, 3062 Defense Pentagon, Washington, DC 20301–3062. Æ Hand Delivery/Courier: Defense Acquisition Regulations System, Crystal Square 4, Suite 200A, 241 18th Street, Arlington, VA 22202–3402. Comments received generally will be posted without change to http:// www.regulations.gov, including any personal information provided. FOR FURTHER INFORMATION CONTACT: Mr. Mark Gomersall, 703–602–0302. The information collection requirements addressed in this notice are available on the World Wide Web at: http:// www.acq.osd.mil/dpap/dars/dfarspgi/ current/index.html. Paper copies are available from Mr. Mark Gomersall, OUSD(AT&L)DPAP(DARS), IMD 3D139, 3062 Defense Pentagon, Washington, DC 20301–3062. SUPPLEMENTARY INFORMATION: Title, Associated Form, and OMB Number: Defense Federal Acquisition Regulation Supplement (DFARS) Part 242, Contract Administration and Audit Services, and related clauses in DFARS Part 252; DD Form 1659, Application for U.S. Government Shipping Documentation/Instructions; OMB Control Number 0704–0250. Needs and Uses: DoD needs this information to perform contract administration functions. DoD uses the information as follows: a. Contract administration offices use the information required by DFARS Subpart 242.11 to determine contractor progress and to identify any factors that may delay contract performance. b. Administrative contracting officers use the information required by DFARS Subpart 242.73 to determine the allowability of insurance/pension costs under Government contracts. c. Contract administration offices and transportation officers use the information required by DFARS 252.242–7003, and submitted on DD Form 1659, in providing Government bills of lading to contractors. d. Contracting officers use the information required by DFARS 252.242–7004 to determine if contractor material management and accounting systems conform to established DoD standards. Affected Public: Businesses or other for-profit and not-for-profit institutions. Annual Burden Hours: 275,960. Number of Respondents: 15,049. E:\FR\FM\05AUN1.SGM 05AUN1 Federal Register / Vol. 74, No. 149 / Wednesday, August 5, 2009 / Notices Responses per Respondent: Approximately 7. Annual Responses: 105,898. Average Burden per Response: Approximately 2.6 hours. Frequency: On occasion. Summary of Information Collection This information collection includes requirements relating to DFARS Part 242, Contract Administration and Audit Services. a. DFARS Subpart 242.11 requires DoD contract administration personnel to conduct production reviews to determine contractor progress and to identify any factors that may delay contract performance. Contractors must provide information needed to support the reviews and must submit production progress reports. b. DFARS Subpart 242.73 contains requirements for Government conduct of contractor insurance/pension reviews. Contractors must provide documentation needed to support the reviews. c. DFARS 252.242–7003 requires contractors to request Government bills of lading by submitting DD Form 1659 to the transportation officer or the contract administration office. d. DFARS 252.242–7004 requires contractors to establish, maintain, and disclose material management and accounting systems. Michele P. Peterson, Editor, Defense Acquisition Regulations System. [FR Doc. E9–18756 Filed 8–4–09; 8:45 am] BILLING CODE 5001–08–P DEPARTMENT OF DEFENSE Department of the Air Force Notice Is Given of the Names of Members of a Performance Review Board for the Department of the Air Force The members of the 2009 Performance Review Board for the U.S. Air Force are: 1. Board President—Gen Roger A. Brady, USAFE/Air Component, Commander/Director Joint Air Competency Center. 2. Lt Gen Loren M. Reno, Commander, Deputy Chief of Staff, Logistics, Installations and Mission Support, Headquarters, United States Air Force. 3. Mr. Tim A. Beyland, Assistant Deputy Chief of Staff for Manpower and Personnel. 4. Dr. Steven F Butler, Air Force Material Command, Executive Director. 5. Mr. Theodore Williams, Auditor General of the United States Air Force. 6. Ms. Tawanda R. Rooney, Director, Intelligence Systems Support Office. 7. Mr. Timothy K. Bridges, Director, Communications, Installations and Mission Support. 8. Ms. Mary Chris Puckett, Director Installations and Logistics. 9. Mr. Joseph McDade, Army. 10. Mr. Charlie E. Williams, Jr., Director, Defense Contract Management Agency. 11. Mr. Ray Longerbeam (Naval Program Support Activity). Additionally, all career status Air Force Tier 3 SES members not included in the above list are eligible to serve on the 2009 Performance Review Board and are hereby nominated for inclusion on an ad hoc basis in the event of absence(s). In addition Mr. Bobby W. Smart, Director, Policy Planning and Resources, United States Air Force and Ms. Audrey Y. Davis, Deputy Assistant Secretary, Financial Operations, United States Air Force are nominated for inclusion on an ad hoc basis for the Tier 2 Performance Review Board in the event of absence(s). 2009. Section 4314(c)(1) through (5) of Title 5, U.S.C., requires each agency to establish, in accordance with regulations, one or more Senior Executive Service performance review boards. The board(s) shall review and evaluate the initial appraisal of senior executives’ performance by supervisors and make recommendations to the appointing authority or rating official relative to the performance of these executives. FOR FURTHER INFORMATION CONTACT: Please direct any written comments or requests for information to Ms. Pereuna Johnson, Chief, Sustainment Division, Senior Executive Management, AF/ DPSS, 1040 Air Force Pentagon, Washington DC 20330–1040 (PH: 703– 695–7677; or via e-mail at pereuna.johnson@pentagon.af.mil.) Bao-Anh Trinh, Air Force Federal Register Liaison Officer. [FR Doc. E9–18673 Filed 8–4–09; 8:45 am] Department of the Air Force. Notice. AGENCY: ACTION: DATES: Effective Date: November 16, srobinson on DSKHWCL6B1PROD with NOTICES SUPPLEMENTARY INFORMATION: VerDate Nov<24>2008 18:54 Aug 04, 2009 Jkt 217001 BILLING CODE 5001–05–P PO 00000 Frm 00026 Fmt 4703 Sfmt 4703 39065 DEPARTMENT OF EDUCATION Office of Innovation and Improvement Charter Schools Program Grants to Non-State Educational Agencies for Planning, Program Design, and Implementation and for Dissemination Catalog of Federal Domestic Assistance (CFDA) Numbers: 84.282B and 84.282C. ACTION: Notice inviting applications for new awards for fiscal year (FY) 2009; correction. SUMMARY: The Department of Education is correcting the notice inviting applications for new awards for FY 2009 for Charter Schools Program Grants to Non-State Educational Agencies for Planning, Program Design, and Implementation and for Dissemination that was published in the Federal Register on July 27, 2009 (74 FR 37020). Correction: (1) On page 37020, in the third column, under Priority, fourth line; and (2) on page 37021, in the first column, first line, the date and page reference for the Federal Register are corrected to read ‘‘November 21, 2008 (73 FR 70627).’’ FOR FURTHER INFORMATION CONTACT: Erin Pfeltz, U.S. Department of Education, 400 Maryland Avenue, SW., room 4W255, Washington, DC 20202–5970. Telephone: (202) 205–3525. If you use a telecommunications device for the deaf (TDD), call the Federal Relay Service (FRS), toll free, at 1–800–877–8339. Individuals with disabilities can obtain this document in an accessible format (e.g., braille, large print, audiotape, or computer diskette) on request to the contact person listed under this section. Electronic Access to this Document: You can view this document, as well as all other documents of this Department published in the Federal Register, in text or Adobe Portable Document Format (PDF) on the Internet at the following site: http://www.ed.gov/news/ fedregister. To use PDF you must have Adobe Acrobat Reader, which is available free at this site. If you have questions about using PDF, call the U.S. Government Printing Office (GPO), toll free, at 1– 888–293–6498; or in the Washington, DC, area at (202) 512–1530. Note: The official version of this document is the document published in the Federal Register. Free Internet access to the official edition of the Federal Register and the Code of Federal Regulations is available on GPO Access at: http://www.gpoaccess.gov/nara/ index.html. E:\FR\FM\05AUN1.SGM 05AUN1

Agencies

[Federal Register Volume 74, Number 149 (Wednesday, August 5, 2009)]
[Notices]
[Pages 39064-39065]
From the Federal Register Online via the Government Printing Office [www.gpo.gov]
[FR Doc No: E9-18756]


=======================================================================
-----------------------------------------------------------------------

DEPARTMENT OF DEFENSE

Defense Acquisition Regulations System


Information Collection Requirement; Defense Federal Acquisition 
Regulation Supplement; Contract Administration and Audit Services (OMB 
Control Number 0704-0250)

AGENCY: Defense Acquisition Regulations System, Department of Defense 
(DoD).

ACTION: Notice and request for comments regarding a proposed extension 
of an approved information collection requirement.

-----------------------------------------------------------------------

SUMMARY: In compliance with Section 3506(c)(2)(A) of the Paperwork 
Reduction Act of 1995 (44 U.S.C. Chapter 35), DoD announces the 
proposed extension of a public information collection requirement and 
seeks public comment on the provisions thereof. DoD invites comments 
on: (a) Whether the proposed collection of information is necessary for 
the proper performance of the functions of DoD, including whether the 
information will have practical utility; (b) the accuracy of the 
estimate of the burden of the proposed information collection; (c) ways 
to enhance the quality, utility, and clarity of the information to be 
collected; and (d) ways to minimize the burden of the information 
collection on respondents, including the use of automated collection 
techniques or other forms of information technology. The Office of 
Management and Budget (OMB) has approved this information collection 
for use through July 31, 2009. DoD proposes that OMB extend its 
approval for use for three additional years.

DATES: DoD will consider all comments received by October 5, 2009.

ADDRESSES: You may submit comments, identified by OMB Control Number 
0704-0250, using any of the following methods:
    [cir] Federal eRulemaking Portal: http://www.regulations.gov. 
Follow the instructions for submitting comments.
    [cir] E-mail: dfars@osd.mil. Include OMB Control Number 0704-0250 
in the subject line of the message.
    [cir] Fax: 703-602-7887.
    [cir] Mail: Defense Acquisition Regulations System, Attn: Mr. Mark 
Gomersall, OUSD(AT&L)DPAP(DARS), IMD 3D139, 3062 Defense Pentagon, 
Washington, DC 20301-3062.
    [cir] Hand Delivery/Courier: Defense Acquisition Regulations 
System, Crystal Square 4, Suite 200A, 241 18th Street, Arlington, VA 
22202-3402.
    Comments received generally will be posted without change to http://www.regulations.gov, including any personal information provided.

FOR FURTHER INFORMATION CONTACT: Mr. Mark Gomersall, 703-602-0302. The 
information collection requirements addressed in this notice are 
available on the World Wide Web at: http://www.acq.osd.mil/dpap/dars/dfarspgi/current/index.html. Paper copies are available from Mr. Mark 
Gomersall, OUSD(AT&L)DPAP(DARS), IMD 3D139, 3062 Defense Pentagon, 
Washington, DC 20301-3062.

SUPPLEMENTARY INFORMATION: 
    Title, Associated Form, and OMB Number: Defense Federal Acquisition 
Regulation Supplement (DFARS) Part 242, Contract Administration and 
Audit Services, and related clauses in DFARS Part 252; DD Form 1659, 
Application for U.S. Government Shipping Documentation/Instructions; 
OMB Control Number 0704-0250.
    Needs and Uses: DoD needs this information to perform contract 
administration functions. DoD uses the information as follows:
    a. Contract administration offices use the information required by 
DFARS Subpart 242.11 to determine contractor progress and to identify 
any factors that may delay contract performance.
    b. Administrative contracting officers use the information required 
by DFARS Subpart 242.73 to determine the allowability of insurance/
pension costs under Government contracts.
    c. Contract administration offices and transportation officers use 
the information required by DFARS 252.242-7003, and submitted on DD 
Form 1659, in providing Government bills of lading to contractors.
    d. Contracting officers use the information required by DFARS 
252.242-7004 to determine if contractor material management and 
accounting systems conform to established DoD standards.
    Affected Public: Businesses or other for-profit and not-for-profit 
institutions.
    Annual Burden Hours: 275,960.
    Number of Respondents: 15,049.

[[Page 39065]]

    Responses per Respondent: Approximately 7.
    Annual Responses: 105,898.
    Average Burden per Response: Approximately 2.6 hours.
    Frequency: On occasion.

Summary of Information Collection

    This information collection includes requirements relating to DFARS 
Part 242, Contract Administration and Audit Services.
    a. DFARS Subpart 242.11 requires DoD contract administration 
personnel to conduct production reviews to determine contractor 
progress and to identify any factors that may delay contract 
performance. Contractors must provide information needed to support the 
reviews and must submit production progress reports.
    b. DFARS Subpart 242.73 contains requirements for Government 
conduct of contractor insurance/pension reviews. Contractors must 
provide documentation needed to support the reviews.
    c. DFARS 252.242-7003 requires contractors to request Government 
bills of lading by submitting DD Form 1659 to the transportation 
officer or the contract administration office.
    d. DFARS 252.242-7004 requires contractors to establish, maintain, 
and disclose material management and accounting systems.

Michele P. Peterson,
Editor, Defense Acquisition Regulations System.
[FR Doc. E9-18756 Filed 8-4-09; 8:45 am]
BILLING CODE 5001-08-P