Agency Information Collection (VAAR Clause 852.236.91) Under OMB Review, 12805-12806 [E8-4708]

Download as PDF pwalker on PROD1PC71 with NOTICES Federal Register / Vol. 73, No. 47 / Monday, March 10, 2008 / Notices information is needed to allow the contracting officer and the contractor to reach a mutually acceptable agreement on how much to pay the contractor for the proposed changes to the contract. It is also used by the contracting officer to determine whether or not to authorize the proposed changes or whether or not additional or alternate cost proposals for changes are needed. An agency may not conduct or sponsor, and a person is not required to respond to a collection of information unless it displays a currently valid OMB control number. The Federal Register Notice with a 60-day comment period soliciting comments on this collection of information was published on December 6, 2007, at pages 68956– 68957. Affected Public: Business or other forprofit; individuals and households; and not-for-profit institutions. Estimated Annual Burden: a. VAAR Clause 852.236–72, Performance of Work by the Contractor—36 hours. b. VAAR Alternate I to Clause 852.236–80, Subcontracts and Work Coordination—1,190 hours. c. VAAR Clause 852.236–82, Payments Under Fixed-Price Construction Contracts (without NAS), including Alternate 1—1,397. d. VAAR Clause 852.236–83, Payments Under Fixed-Price Construction Contracts (with NAS), including Alternate 1—59 hours. e. VAAR Clause 852.236–84, Schedule of Work Progress—2,095 hours. f. VAAR Clause 852.236–88, Contract Changes, Supplements FAR Clause 52.243–4, Changes—807 hours. Estimated Average Burden per Respondent: a. VAAR Clause 852.236–72, Performance of Work by the Contractor—1 hour. b. VAAR Alternate I to Clause 852.236–80, Subcontracts and Work Coordination—10 hours. c. VAAR Clause 852.236–82, Payments Under Fixed-Price Construction Contracts (without NAS), including Alternate 1—1 hour. d. VAAR Clause 852.236–83, Payments Under Fixed-Price Construction Contracts (with NAS), including Alternate 1—30 minutes. e. VAAR Clause 852.236–84, Schedule of Work Progress—1 hour. f. VAAR Clause 852.236–88, Contract Changes, Supplements FAR Clause 52.243–4, Changes—3 hours. Frequency of Response: On occasion. Estimated Number of Respondents: a. VAAR Clause 852.236–72, Performance of Work by the Contractor—36. VerDate Aug<31>2005 16:39 Mar 07, 2008 Jkt 214001 b. VAAR Alternate I to Clause 852.236–80, Subcontracts and Work Coordination—119. c. Department of Veterans Affairs Acquisition Regulation (VAAR) Clause 852.236–82, Payments Under FixedPrice Construction Contracts (without NAS), including Alternate 1—1,397. d. VAAR Clause 852.236–83, Payments Under Fixed-Price Construction Contracts (with NAS), including Alternate 1—119. e. VAAR Clause 852.236–84, Schedule of Work Progress—1,397. f. VAAR Clause 852.236–88, Contract Changes, Supplements FAR Clause 52.243–4, Changes—269. Dated: February 27, 2008. By direction of the Secretary. Denise McLamb, Program Analyst, Records Management Service. [FR Doc. E8–4704 Filed 3–7–08; 8:45 am] BILLING CODE 8320–01–P DEPARTMENT OF VETERANS AFFAIRS [OMB Control No. 2900–0623] Agency Information Collection (VAAR Clause 852.236.91) Under OMB Review Office of Management, Department of Veterans Affairs. ACTION: Notice. AGENCY: SUMMARY: In compliance with the Paperwork Reduction Act (PRA) of 1995 (44 U.S.C. 3501–3521), this notice announces that the Office of Management (OM), Department of Veterans Affairs, will submit the collection of information abstracted below to the Office of Management and Budget (OMB) for review and comment. The PRA submission describes the nature of the information collection and its expected cost and burden; it includes the actual data collection instrument. DATES: Comments must be submitted on or before April 9, 2008. ADDRESSES: Submit written comments on the collection of information through https://www.Regulations.gov; or to VA’s OMB Desk Officer, OMB Human Resources and Housing Branch, New Executive Office Building, Room 10235, Washington, DC 20503 (202) 395–7316. Please refer to ‘‘OMB Control No. 2900– 0623’’ in any correspondence. FOR FURTHER INFORMATION OR A COPY OF THE SUBMISSION CONTACT: Denise McLamb, Records Management Service (005R1B), Department of Veterans Affairs, 810 Vermont Avenue, NW., Washington, DC 20420, (202) 461–7485, PO 00000 Frm 00104 Fmt 4703 Sfmt 4703 12805 FAX (202) 273–0443 or e-mail: denise.mclamb@mail.va.gov. Please refer to ‘‘OMB Control No. 2900–0623.’’ SUPPLEMENTARY INFORMATION: Under the PRA of 1995 (Pub. L. 104–13; 44 U.S.C. 3501–3521), Federal agencies must obtain approval from the Office of Management and Budget (OMB) for each collection of information they conduct or sponsor. This request for comment is being made pursuant to section 3506(c)(2)(A) of the PRA. With respect to the following collection of information, OM invites comments on: (1) Whether the proposed collection of information is necessary for the proper performance of OM’s functions, including whether the information will have practical utility; (2) the accuracy of OM’s estimate of the burden of the proposed collection of information; (3) ways to enhance the quality, utility, and clarity of the information to be collected; and (4) ways to minimize the burden of the collection of information on respondents, including through the use of automated collection techniques or the use of other forms of information technology. Title: Department of Veterans Affairs Acquisition Regulation (VAAR) Clause 852.236.91. OMB Control Number: 2900–0623. Type of Review: Extension of a currently approved. Abstract: VAAR Clause 852.236.91 requires bidders to furnish information on previous experience, technical qualifications, financial resources, and facilities available to perform the work. The clause also requires contractors submitting a claim for price adjustment due to severe weather delay to provide climatologically data covering the period of the claim and covering the same period for the ten preceding years. VA uses the data collected to evaluate the bidder’s qualification and responsibility, and to evaluate the contractor’s claims for contract price adjustment due to weather-related delays. An agency may not conduct or sponsor, and a person is not required to respond to a collection of information unless it displays a currently valid OMB control number. The Federal Register Notice with a 60-day comment period soliciting comments on this collection of information was published on December 6, 2007, at pages 68957– 68958. Affected Public: Business or other forprofit; Individuals and households; and not-for-profit institutions. Estimated Annual Burden: 778 hours. a. Qualifications Data: 758 hours. E:\FR\FM\10MRN1.SGM 10MRN1 12806 Federal Register / Vol. 73, No. 47 / Monday, March 10, 2008 / Notices pwalker on PROD1PC71 with NOTICES b. Weather Data: 20 hours. Estimated Average Burden per Respondent: a. Qualifications Data: 30 min. b. Weather Data: 1 hour. Frequency of Response: On occasion. VerDate Aug<31>2005 16:39 Mar 07, 2008 Jkt 214001 Estimated Number of Respondents: 1,536. a. Qualifications Data: 1516. b. Weather Data: 20. Dated: February 27, 2008. PO 00000 Frm 00105 Fmt 4703 Sfmt 4703 By direction of the Secretary. Denise McLamb, Program Analyst, Records Management Service. [FR Doc. E8–4708 Filed 3–7–08; 8:45 am] BILLING CODE 8320–01–P E:\FR\FM\10MRN1.SGM 10MRN1

Agencies

[Federal Register Volume 73, Number 47 (Monday, March 10, 2008)]
[Notices]
[Pages 12805-12806]
From the Federal Register Online via the Government Printing Office [www.gpo.gov]
[FR Doc No: E8-4708]


-----------------------------------------------------------------------

DEPARTMENT OF VETERANS AFFAIRS

[OMB Control No. 2900-0623]


Agency Information Collection (VAAR Clause 852.236.91) Under OMB 
Review

AGENCY: Office of Management, Department of Veterans Affairs.

ACTION: Notice.

-----------------------------------------------------------------------

SUMMARY: In compliance with the Paperwork Reduction Act (PRA) of 1995 
(44 U.S.C. 3501-3521), this notice announces that the Office of 
Management (OM), Department of Veterans Affairs, will submit the 
collection of information abstracted below to the Office of Management 
and Budget (OMB) for review and comment. The PRA submission describes 
the nature of the information collection and its expected cost and 
burden; it includes the actual data collection instrument.

DATES: Comments must be submitted on or before April 9, 2008.

ADDRESSES: Submit written comments on the collection of information 
through https://www.Regulations.gov; or to VA's OMB Desk Officer, OMB 
Human Resources and Housing Branch, New Executive Office Building, Room 
10235, Washington, DC 20503 (202) 395-7316. Please refer to ``OMB 
Control No. 2900-0623'' in any correspondence.

For Further Information Or a Copy of the Submission Contact: Denise 
McLamb, Records Management Service (005R1B), Department of Veterans 
Affairs, 810 Vermont Avenue, NW., Washington, DC 20420, (202) 461-7485, 
FAX (202) 273-0443 or e-mail: denise.mclamb@mail.va.gov. Please refer 
to ``OMB Control No. 2900-0623.''

SUPPLEMENTARY INFORMATION: Under the PRA of 1995 (Pub. L. 104-13; 44 
U.S.C. 3501-3521), Federal agencies must obtain approval from the 
Office of Management and Budget (OMB) for each collection of 
information they conduct or sponsor. This request for comment is being 
made pursuant to section 3506(c)(2)(A) of the PRA.
    With respect to the following collection of information, OM invites 
comments on: (1) Whether the proposed collection of information is 
necessary for the proper performance of OM's functions, including 
whether the information will have practical utility; (2) the accuracy 
of OM's estimate of the burden of the proposed collection of 
information; (3) ways to enhance the quality, utility, and clarity of 
the information to be collected; and (4) ways to minimize the burden of 
the collection of information on respondents, including through the use 
of automated collection techniques or the use of other forms of 
information technology.
    Title: Department of Veterans Affairs Acquisition Regulation (VAAR) 
Clause 852.236.91.
    OMB Control Number: 2900-0623.
    Type of Review: Extension of a currently approved.
    Abstract: VAAR Clause 852.236.91 requires bidders to furnish 
information on previous experience, technical qualifications, financial 
resources, and facilities available to perform the work. The clause 
also requires contractors submitting a claim for price adjustment due 
to severe weather delay to provide climatologically data covering the 
period of the claim and covering the same period for the ten preceding 
years. VA uses the data collected to evaluate the bidder's 
qualification and responsibility, and to evaluate the contractor's 
claims for contract price adjustment due to weather-related delays.
    An agency may not conduct or sponsor, and a person is not required 
to respond to a collection of information unless it displays a 
currently valid OMB control number. The Federal Register Notice with a 
60-day comment period soliciting comments on this collection of 
information was published on December 6, 2007, at pages 68957-68958.
    Affected Public: Business or other for-profit; Individuals and 
households; and not-for-profit institutions.
    Estimated Annual Burden: 778 hours.
    a. Qualifications Data: 758 hours.

[[Page 12806]]

    b. Weather Data: 20 hours.
    Estimated Average Burden per Respondent:
    a. Qualifications Data: 30 min.
    b. Weather Data: 1 hour.
    Frequency of Response: On occasion.
    Estimated Number of Respondents: 1,536.
    a. Qualifications Data: 1516.
    b. Weather Data: 20.

    Dated: February 27, 2008.

    By direction of the Secretary.
Denise McLamb,
Program Analyst, Records Management Service.
[FR Doc. E8-4708 Filed 3-7-08; 8:45 am]
BILLING CODE 8320-01-P
This site is protected by reCAPTCHA and the Google Privacy Policy and Terms of Service apply.