Federal Acquisition Regulation; Information Collection; Schedules for Construction Contracts, 4821 [05-1692]

Download as PDF Federal Register / Vol. 70, No. 19 / Monday, January 31, 2005 / Notices CORPORATION FOR NATIONAL AND COMMUNITY SERVICE Sunshine Act Notice DEPARTMENT OF DEFENSE GENERAL SERVICES ADMINISTRATION The Board of Directors of the Corporation for National and Community Service gives notice of the following meeting: NATIONAL AERONAUTICS AND SPACE ADMINISTRATION Tuesday, February 8, 2005, 10 a.m.–12 p.m. Federal Acquisition Regulation; Information Collection; Schedules for Construction Contracts DATE AND TIME: Corporation for National and Community Service, 1201 New York Avenue, NW., 8th Floor, Room 8410, Washington, DC 20525. PLACE: STATUS: Open. MATTERS TO BE CONSIDERED: I. Chair’s Opening Remarks II. Administration of Oath of Office for Board Members III. Consideration of Prior Meeting’s Minutes IV. Chief Executive Officer’s Report V. Committee Reports VI. Public Comment. To help in developing a five-year strategic plan, the Board of Directors is particularly interested in any comments from the public concerning the future goals and strategies for the Corporation over the next five years. VII. Adjourn Anyone who needs an interpreter or other accommodation should notify the Corporation’s contact person by 5 p.m. Friday, February 4, 2005. ACCOMMODATIONS: FOR FURTHER INFORMATION CONTACT: David Premo, Public Affairs Associate, Public Affairs, Corporation for National and Community Service, 8th Floor, Room 8612C, 1201 New York Avenue NW., Washington, DC 20525. Phone (202) 606–5000 ext. 278. Fax (202) 565– 2784. TDD: (202) 565–2799. E-mail: dpremo@cns.gov. Dated: January 26, 2005. Frank R. Trinity, General Counsel. [FR Doc. 05–1847 Filed 1–27–05; 1:53 pm] BILLING CODE 6050–$$–P [OMB Control No. 9000–0058] Department of Defense (DOD), General Services Administration (GSA), and National Aeronautics and Space Administration (NASA). ACTION: Notice of request for an extension to an existing OMB clearance. AGENCIES: SUMMARY: Under the provisions of the Paperwork Reduction Act of 1995 (44 U.S.C. Chapter 35), the Federal Acquisition Regulation (FAR) Secretariat will be submitting to the Office of Management and Budget (OMB) a request to review and approve an extension of a currently approved information collection requirement concerning schedules for construction contracts. The clearance currently expires on May 31, 2005. Public comments are particularly invited on: Whether this collection of information is necessary for the proper performance of functions of the FAR, and whether it will have practical utility; whether our estimate of the public burden of this collection of information is accurate, and based on valid assumptions and methodology; ways to enhance the quality, utility, and clarity of the information to be collected; and ways in which we can minimize the burden of the collection of information on those who are to respond, through the use of appropriate technological collection techniques or other forms of information technology. DATES: Submit comments on or before April 1, 2005. ADDRESSES: Submit comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden to the General Services Administration, FAR Secretariat (VIR), 1800 F Street, NW, Room 4035, Washington, DC 20405. Please cite OMB Control No.9000–0058, schedules for construction contracts, in all correspondence. FOR FURTHER INFORMATION CONTACT Cecelia Davis, Contract Policy Division, GSA (202) 219–0202. SUPPLEMENTARY INFORMATION: VerDate jul<14>2003 17:46 Jan 28, 2005 Jkt 205001 PO 00000 Frm 00010 Fmt 4703 Sfmt 4703 4821 A. Purpose Federal construction contractors may be required to submit schedules, in the form of a progress chart, showing the order in which the contractor proposes to perform the work. Actual progress shall be entered on the chart as directed by the contracting officer. This information is used to monitor progress under a Federal construction contract when other management approaches for ensuring adequate progress are not used. B. Annual Reporting Burden Respondents: 2,600. Responses Per Respondent: 2. Annual Responses: 5,200. Hours Per Response: 1. Total Burden Hours: 5,200. Obtaining Copies of Proposals: Requesters may obtain a copy of the information collection documents from the General Services Administration, FAR Secretariat (VIR), Room 4035, 1800 F Street, NW, Washington, DC 20405, telephone (202) 501–4755. Please cite OMB Control No. 9000–0058, Schedules for Construction Contracts, in all correspondence. Dated: January 19, 2005 Laura Auletta Director,Contract Policy Division [FR Doc. 05–1692 Filed 1–28–05; 8:45 am] BILLING CODE 6820–EP–S DEPARTMENT OF DEFENSE Office of the Secretary Meeting of the Defense Department Advisory Committee on Women in the Services (DACOWITS) Department of Defense. Notice. AGENCY: ACTION: SUMMARY: Pursuant to section 10(a), Public Law 92–463, as amended, notice is hereby given of a forthcoming meeting of the Defense Department Advisory Committee on Women in the Services (DACOWITS). The purpose of the Committee meeting is to discuss the 2004 DACOWITS Report. The meeting is open to the public, subject to the availability of space. Interested persons may submit a written statement for consideration by the Committee and make an oral presentation of such. Persons desiring to make an oral presentation or submit a written statement to the Committee must notify the point of contact listed below no later than 5 p.m., February 1, 2005. Oral presentations by members of the public will be permitted only on Thursday, February 3, 2005, from 4:30 p.m. to 4:45 p.m. before the full E:\FR\FM\31JAN1.SGM 31JAN1

Agencies

[Federal Register Volume 70, Number 19 (Monday, January 31, 2005)]
[Notices]
[Page 4821]
From the Federal Register Online via the Government Printing Office [www.gpo.gov]
[FR Doc No: 05-1692]


=======================================================================
-----------------------------------------------------------------------

DEPARTMENT OF DEFENSE

GENERAL SERVICES ADMINISTRATION

NATIONAL AERONAUTICS AND SPACE ADMINISTRATION

[OMB Control No. 9000-0058]


Federal Acquisition Regulation; Information Collection; Schedules 
for Construction Contracts

AGENCIES: Department of Defense (DOD), General Services Administration 
(GSA), and National Aeronautics and Space Administration (NASA).

ACTION: Notice of request for an extension to an existing OMB 
clearance.

-----------------------------------------------------------------------

SUMMARY: Under the provisions of the Paperwork Reduction Act of 1995 
(44 U.S.C. Chapter 35), the Federal Acquisition Regulation (FAR) 
Secretariat will be submitting to the Office of Management and Budget 
(OMB) a request to review and approve an extension of a currently 
approved information collection requirement concerning schedules for 
construction contracts. The clearance currently expires on May 31, 
2005.
    Public comments are particularly invited on: Whether this 
collection of information is necessary for the proper performance of 
functions of the FAR, and whether it will have practical utility; 
whether our estimate of the public burden of this collection of 
information is accurate, and based on valid assumptions and 
methodology; ways to enhance the quality, utility, and clarity of the 
information to be collected; and ways in which we can minimize the 
burden of the collection of information on those who are to respond, 
through the use of appropriate technological collection techniques or 
other forms of information technology.

DATES: Submit comments on or before April 1, 2005.

ADDRESSES: Submit comments regarding this burden estimate or any other 
aspect of this collection of information, including suggestions for 
reducing this burden to the General Services Administration, FAR 
Secretariat (VIR), 1800 F Street, NW, Room 4035, Washington, DC 20405. 
Please cite OMB Control No.9000-0058, schedules for construction 
contracts, in all correspondence.

FOR FURTHER INFORMATION CONTACT Cecelia Davis, Contract Policy 
Division, GSA (202) 219-0202.

SUPPLEMENTARY INFORMATION:

A. Purpose

    Federal construction contractors may be required to submit 
schedules, in the form of a progress chart, showing the order in which 
the contractor proposes to perform the work. Actual progress shall be 
entered on the chart as directed by the contracting officer. This 
information is used to monitor progress under a Federal construction 
contract when other management approaches for ensuring adequate 
progress are not used.

B. Annual Reporting Burden

    Respondents: 2,600.
    Responses Per Respondent: 2.
    Annual Responses: 5,200.
    Hours Per Response: 1.
    Total Burden Hours: 5,200.
    Obtaining Copies of Proposals: Requesters may obtain a copy of the 
information collection documents from the General Services 
Administration, FAR Secretariat (VIR), Room 4035, 1800 F Street, NW, 
Washington, DC 20405, telephone (202) 501-4755. Please cite OMB Control 
No. 9000-0058, Schedules for Construction Contracts, in all 
correspondence.

    Dated: January 19, 2005
Laura Auletta
Director,Contract Policy Division
[FR Doc. 05-1692 Filed 1-28-05; 8:45 am]
BILLING CODE 6820-EP-S

This site is protected by reCAPTCHA and the Google Privacy Policy and Terms of Service apply.