Submission for OMB Review; Use of Project Labor Agreements for Federal Construction Projects, 22602-22603 [2016-08873]

Download as PDF 22602 Federal Register / Vol. 81, No. 74 / Monday, April 18, 2016 / Notices Notice of request for public comments regarding an extension to an existing OMB clearance. ACTION: Under the provisions of the Paperwork Reduction Act, the Regulatory Secretariat Division will be submitting to the Office of Management and Budget (OMB) a request to review and approve an extension of a previously approved information collection requirement concerning Taxpayer Identification Number Information. A notice was published in the Federal Register at 81 FR 6514 on February 8, 2016. No comments were received. SUMMARY: Submit comments on or before May 18, 2016. ADDRESSES: Submit comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden to: Office of Information and Regulatory Affairs of OMB, Attention: Desk Officer for GSA, Room 10236, NEOB, Washington, DC 20503. Additionally submit a copy to GSA by any of the following methods: • Regulations.gov: https:// www.regulations.gov. Submit comments via the Federal eRulemaking portal by searching the OMB control number. Select the link ‘‘Submit a Comment’’ that corresponds with ‘‘Information Collection 9000–0097, Taxpayer Identification Number Information’’. Follow the instructions provided at the ‘‘Submit a Comment’’ screen. Please include your name, company name (if any), and ‘‘Information Collection 9000– 0097, Taxpayer Identification Number Information’’ on your attached document. • Mail: General Services Administration, Regulatory Secretariat Division (MVCB), 1800 F Street NW., Washington, DC 20405. ATTN: Ms. Flowers/IC 9000–0097, Taxpayer Identification Number Information. Instructions: Please submit comments only and cite Information Collection 9000–0097, Taxpayer Identification Number Information, in all correspondence related to this collection. Comments received generally will be posted without change to https:// www.regulations.gov, including any personal and/or business confidential information provided. To confirm receipt of your comment(s), please check www.regulations.gov, approximately two to three days after submission to verify posting (except allow 30 days for posting of comments submitted by mail). FOR FURTHER INFORMATION CONTACT: Mr. Curtis E. Glover, Sr., Procurement mstockstill on DSK4VPTVN1PROD with NOTICES DATES: VerDate Sep<11>2014 17:54 Apr 15, 2016 Jkt 238001 Analyst, Contract Policy Division, GSA, 202–501–1448 or email at curtis.glover@ gsa.gov. SUPPLEMENTARY INFORMATION: A. Purpose In accordance with 31 U.S.C. 7701(c), a contractor doing business with a Government agency is required to furnish its Tax Identification Number (TIN) to that agency. Also, 31 U.S.C. 3325(d) requires the Government to include, with each certified voucher prepared by the Government payment office and submitted to a disbursing official, the TIN of the contractor receiving payment under the voucher. 26 U.S.C. 6050M, as implemented in the Department of Treasury, Internal Revenue Service (IRS) regulations at Title 26 of the Code of Federal Regulations (CFR), requires heads of Federal executive agencies to report certain information to the IRS. 26 U.S.C. 6041 and 6041A, as implemented in 26 CFR, in part, requires payors, including Government agencies, to report to the IRS, on form 1099, payments made to certain contractors. To comply with the requirements of 31 U.S.C. 7701(c) and 3325(d), reporting requirements of 26 U.S.C. 6041, 6041A, and 6050M, and implementing regulations issued by the IRS in 26 CFR, FAR clause 52.204–3, Taxpayer Identification, requires a potential Government contractor to submit, among other information, its TIN. The TIN may be used by the Government to collect and report on any delinquent amounts arising out of the contractor’s relationship with the Government. A contractor is not required to provide its TIN on each contract in accordance with FAR clause 52.204–3, Taxpayer Identification, when FAR clause 52.204–7, Central Contractor Registration, is inserted in contracts. FAR clause 52.204–7 requires a potential Federal contractor to provide its TIN in the Central Contractor Registration (CCR) system. B. Annual Reporting Burden Respondents: 39,428. Responses Per Respondent: 3. Total Responses: 118,284. Hours Per Response: 10. Total Burden Hours: 11,828. C. Public Comments Public comments are particularly invited on: Whether this collection of information is necessary for the proper performance of functions of the Federal Acquisition Regulation (FAR), and whether it will have practical utility; whether our estimate of the public burden of this collection of information PO 00000 Frm 00036 Fmt 4703 Sfmt 4703 is accurate, and based on valid assumptions and methodology; ways to enhance the quality, utility, and clarity of the information to be collected; and ways in which we can minimize the burden of the collection of information on those who are to respond, through the use of appropriate technological collection techniques or other forms of information technology. Obtaining Copies of Proposals: Requesters may obtain a copy of the information collection documents from the General Services Administration, Regulatory Secretariat Division (MVCB), 1800 F Street NW., Washington, DC 20405, telephone 202–501–4755. Please cite OMB Control No. 9000–0097, Taxpayer Identification Number Information, in all correspondence. Dated: April 13, 2016. Lorin S. Curit, Director, Federal Acquisition Policy Division, Office of Governmentwide Acquisition Policy, Office of Acquisition Policy, Office of Governmentwide Policy. [FR Doc. 2016–08871 Filed 4–15–16; 8:45 am] BILLING CODE 6820–EP–P DEPARTMENT OF DEFENSE GENERAL SERVICES ADMINISTRATION NATIONAL AERONAUTICS AND SPACE ADMINISTRATION [OMB Control No. 9000–0175; Docket 2016– 0053; Sequence 5] Submission for OMB Review; Use of Project Labor Agreements for Federal Construction Projects Department of Defense (DOD), General Services Administration (GSA), and National Aeronautics and Space Administration (NASA). ACTION: Notice of request for public comments regarding an extension to an existing OMB clearance. AGENCY: Under the provisions of the Paperwork Reduction Act of 1995, the Regulatory Secretariat Division will be submitting to the Office of Management and Budget (OMB) a request to review and approve a new information collection requirement regarding Use of Project Labor Agreements for Federal Construction Projects. A notice published in the Federal Register at 81 FR 6516 on February 8, 2016. No comments were received. DATES: Submit comments on or before May 18, 2016. ADDRESSES: Submit comments regarding this burden estimate or any other aspect SUMMARY: E:\FR\FM\18APN1.SGM 18APN1 Federal Register / Vol. 81, No. 74 / Monday, April 18, 2016 / Notices of this collection of information, including suggestions for reducing this burden to: Office of Information and Regulatory Affairs of OMB, Attention: Desk Officer for GSA, Room 10236, NEOB, Washington, DC 20503. Additionally submit a copy to GSA by any of the following methods: • Regulations.gov: https:// www.regulations.gov. Submit comments via the Federal eRulemaking portal by searching the OMB control number. Select the link ‘‘Submit a Comment’’ that corresponds with ‘‘Information Collection 9000–0175, Use of Project Labor Agreements for Federal Construction Projects’’. Follow the instructions provided at the ‘‘Submit a Comment’’ screen. Please include your name, company name (if any), and ‘‘Information Collection 9000–0175, Use of Project Labor Agreements for Federal Construction Projects’’ on your attached document. • Mail: General Services Administration, Regulatory Secretariat Division (MVCB), 1800 F Street NW., Washington, DC 20405. ATTN: Ms. Flowers/IC 9000–0175, Use of Project Labor Agreements for Federal Construction Projects. Instructions: Please submit comments only and cite Information Collection 9000–0175, Use of Project Labor Agreements for Federal Construction Projects, in all correspondence related to this collection. Comments received generally will be posted without change to https://www.regulations.gov, including any personal and/or business confidential information provided. To confirm receipt of your comment(s), please check www.regulations.gov, approximately two to three days after submission to verify posting (except allow 30 days for posting of comments submitted by mail). FOR FURTHER INFORMATION CONTACT: Mr. Edward Loeb, Procurement Analyst, Office of Governmentwide Acquisition Policy, at telephone 202–501–0650 or via email to edward.loeb@gsa.gov. SUPPLEMENTARY INFORMATION: mstockstill on DSK4VPTVN1PROD with NOTICES A. Purpose FAR 22.501 prescribes policies and procedures to implement Executive Order 13502, February 6, 2009 which encourages Federal agencies to consider the use of a project labor agreement (PLA), as they may decide appropriate, on large-scale construction projects, where the total cost to the Government is more than $25 million, in order to promote economy and efficiency in Federal procurement. A PLA is a prehire collective bargaining agreement with one or more labor organizations VerDate Sep<11>2014 17:54 Apr 15, 2016 Jkt 238001 that establishes the terms and conditions of employment for a specific construction project. FAR 22.503(b) provides that an agency may, if appropriate, require that every contractor and subcontractor engaged in construction on the project agree, for that project, to negotiate or become a party to a project labor agreement with one or more labor organizations if the agency decides that the use of project labor agreements will— (1) Advance the Federal Government’s interest in achieving economy and efficiency in Federal procurement, producing labor-management stability, and ensuring compliance with laws and regulations governing safety and health, equal employment opportunity, labor and employment standards, and other matters; and, (2) Be consistent with law. B. Annual Reporting Burden Respondents: 70. Responses per Respondent: 1. Annual Responses: 70. Hours per Response: 1. Total Burden Hours: 70. C. Public Comments Public comments are particularly invited on: Whether this collection of information is necessary for the proper performance of functions of the FAR, and whether it will have practical utility; whether our estimate of the public burden of this collection of information is accurate, and based on valid assumptions and methodology; ways to enhance the quality, utility, and clarity of the information to be collected; and ways in which we can minimize the burden of the collection of information on those who are to respond, through the use of appropriate technological collection techniques or other forms of information technology. Obtaining Copies of Proposals: Requesters may obtain a copy of the information collection documents from the General Services Administration, Regulatory Secretariat Division (MVCB), 1800 F Street NW., Washington, DC 20405, telephone 202–501–4755. Please cite OMB Control No. 9000–0175, Use of Project Labor Agreements for Federal Construction Projects, in all correspondence. Dated: April 13, 2016. Lorin S. Curit, Director, Federal Acquisition Policy Division, Office of Governmentwide Acquisition Policy, Office of Acquisition Policy, Office of Governmentwide Policy. [FR Doc. 2016–08873 Filed 4–15–16; 8:45 am] BILLING CODE 6820–EP–P PO 00000 Frm 00037 Fmt 4703 Sfmt 4703 22603 DEPARTMENT OF DEFENSE GENERAL SERVICES ADMINISTRATION NATIONAL AERONAUTICS AND SPACE ADMINISTRATION [OMB Control No. 9000–0060; Docket 2016– 0053; Sequence 5] Submission for OMB Review; Accident Prevention Plans and Recordkeeping Department of Defense (DOD), General Services Administration (GSA), and National Aeronautics and Space Administration (NASA). ACTION: Notice of request for an extension of an information collection requirement regarding an existing OMB clearance. AGENCY: Under the provisions of the Paperwork Reduction Act, Regulatory Secretariat Division will be submitting to the Office of Management and Budget (OMB) a request to review and approve an extension of a previously approved information collection requirement concerning Accident Prevention Plans and Recordkeeping. A notice published in the Federal Register at 81 FR 6517 on February 8, 2016. No comments were received. SUMMARY: Submit comments on or before May 18, 2016. ADDRESSES: Submit comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden to: Office of Information and Regulatory Affairs of OMB, Attention: Desk Officer for GSA, Room 10236, NEOB, Washington, DC 20503. Additionally submit a copy to GSA by any of the following methods: • Regulations.gov: https:// www.regulations.gov. Submit comments via the Federal eRulemaking portal by searching for Information Collection 9000–0060, Accident Prevention Plans and Recordkeeping. Select the link ‘‘Comment Now’’ that corresponds with ‘‘Information Collection 9000–0060, Accident Prevention Plans and Recordkeeping’’. Follow the instructions provided on the screen. Please include your name, company name (if any), and ‘‘Information Collection 9000–0060, Accident Prevention Plans and Recordkeeping’’ on your attached document. • Mail: General Services Administration, Regulatory Secretariat Division (MVCB), 1800 F Street NW., Washington, DC 20405. ATTN: Ms. Flowers/IC 9000–0060, Accident Prevention Plans and Recordkeeping. DATES: E:\FR\FM\18APN1.SGM 18APN1

Agencies

[Federal Register Volume 81, Number 74 (Monday, April 18, 2016)]
[Notices]
[Pages 22602-22603]
From the Federal Register Online via the Government Publishing Office [www.gpo.gov]
[FR Doc No: 2016-08873]


-----------------------------------------------------------------------

DEPARTMENT OF DEFENSE

GENERAL SERVICES ADMINISTRATION

NATIONAL AERONAUTICS AND SPACE ADMINISTRATION

[OMB Control No. 9000-0175; Docket 2016-0053; Sequence 5]


Submission for OMB Review; Use of Project Labor Agreements for 
Federal Construction Projects

AGENCY: Department of Defense (DOD), General Services Administration 
(GSA), and National Aeronautics and Space Administration (NASA).

ACTION: Notice of request for public comments regarding an extension to 
an existing OMB clearance.

-----------------------------------------------------------------------

SUMMARY: Under the provisions of the Paperwork Reduction Act of 1995, 
the Regulatory Secretariat Division will be submitting to the Office of 
Management and Budget (OMB) a request to review and approve a new 
information collection requirement regarding Use of Project Labor 
Agreements for Federal Construction Projects. A notice published in the 
Federal Register at 81 FR 6516 on February 8, 2016. No comments were 
received.

DATES: Submit comments on or before May 18, 2016.

ADDRESSES: Submit comments regarding this burden estimate or any other 
aspect

[[Page 22603]]

of this collection of information, including suggestions for reducing 
this burden to: Office of Information and Regulatory Affairs of OMB, 
Attention: Desk Officer for GSA, Room 10236, NEOB, Washington, DC 
20503. Additionally submit a copy to GSA by any of the following 
methods:
     Regulations.gov: https://www.regulations.gov. Submit 
comments via the Federal eRulemaking portal by searching the OMB 
control number. Select the link ``Submit a Comment'' that corresponds 
with ``Information Collection 9000-0175, Use of Project Labor 
Agreements for Federal Construction Projects''. Follow the instructions 
provided at the ``Submit a Comment'' screen. Please include your name, 
company name (if any), and ``Information Collection 9000-0175, Use of 
Project Labor Agreements for Federal Construction Projects'' on your 
attached document.
     Mail: General Services Administration, Regulatory 
Secretariat Division (MVCB), 1800 F Street NW., Washington, DC 20405. 
ATTN: Ms. Flowers/IC 9000-0175, Use of Project Labor Agreements for 
Federal Construction Projects.
    Instructions: Please submit comments only and cite Information 
Collection 9000-0175, Use of Project Labor Agreements for Federal 
Construction Projects, in all correspondence related to this 
collection. Comments received generally will be posted without change 
to https://www.regulations.gov, including any personal and/or business 
confidential information provided. To confirm receipt of your 
comment(s), please check www.regulations.gov, approximately two to 
three days after submission to verify posting (except allow 30 days for 
posting of comments submitted by mail).

FOR FURTHER INFORMATION CONTACT: Mr. Edward Loeb, Procurement Analyst, 
Office of Governmentwide Acquisition Policy, at telephone 202-501-0650 
or via email to edward.loeb@gsa.gov.

SUPPLEMENTARY INFORMATION:

A. Purpose

    FAR 22.501 prescribes policies and procedures to implement 
Executive Order 13502, February 6, 2009 which encourages Federal 
agencies to consider the use of a project labor agreement (PLA), as 
they may decide appropriate, on large-scale construction projects, 
where the total cost to the Government is more than $25 million, in 
order to promote economy and efficiency in Federal procurement. A PLA 
is a pre-hire collective bargaining agreement with one or more labor 
organizations that establishes the terms and conditions of employment 
for a specific construction project. FAR 22.503(b) provides that an 
agency may, if appropriate, require that every contractor and 
subcontractor engaged in construction on the project agree, for that 
project, to negotiate or become a party to a project labor agreement 
with one or more labor organizations if the agency decides that the use 
of project labor agreements will--
    (1) Advance the Federal Government's interest in achieving economy 
and efficiency in Federal procurement, producing labor-management 
stability, and ensuring compliance with laws and regulations governing 
safety and health, equal employment opportunity, labor and employment 
standards, and other matters; and,
    (2) Be consistent with law.

B. Annual Reporting Burden

    Respondents: 70.
    Responses per Respondent: 1.
    Annual Responses: 70.
    Hours per Response: 1.
    Total Burden Hours: 70.

C. Public Comments

    Public comments are particularly invited on: Whether this 
collection of information is necessary for the proper performance of 
functions of the FAR, and whether it will have practical utility; 
whether our estimate of the public burden of this collection of 
information is accurate, and based on valid assumptions and 
methodology; ways to enhance the quality, utility, and clarity of the 
information to be collected; and ways in which we can minimize the 
burden of the collection of information on those who are to respond, 
through the use of appropriate technological collection techniques or 
other forms of information technology.
    Obtaining Copies of Proposals: Requesters may obtain a copy of the 
information collection documents from the General Services 
Administration, Regulatory Secretariat Division (MVCB), 1800 F Street 
NW., Washington, DC 20405, telephone 202-501-4755. Please cite OMB 
Control No. 9000-0175, Use of Project Labor Agreements for Federal 
Construction Projects, in all correspondence.

    Dated: April 13, 2016.
Lorin S. Curit,
Director, Federal Acquisition Policy Division, Office of Governmentwide 
Acquisition Policy, Office of Acquisition Policy, Office of 
Governmentwide Policy.
[FR Doc. 2016-08873 Filed 4-15-16; 8:45 am]
 BILLING CODE 6820-EP-P
This site is protected by reCAPTCHA and the Google Privacy Policy and Terms of Service apply.